XML 11 R17.htm IDEA: XBRL DOCUMENT
v2.4.0.8

Commitments and Contingencies | 9 Months Ended
--- | ---
Sep. 30, 2013
Commitments And Contingencies Disclosure [Abstract] |
Commitments and Contingencies |
10. | COMMITMENTS AND CONTINGENCIES:
Investments in Affiliates and Other Entities As described in Note 8, Quanta holds investments in certain joint ventures with third parties for the purpose of providing infrastructure services under certain customer contracts. Losses incurred by these joint ventures are shared equally by the joint venture members. However, each member of the joint venture is jointly and severally liable for all of the obligations of the joint venture under the contract with the customer and therefore can be liable for full performance of the contract with the customer. In circumstances where Quanta’s participation in a joint venture qualifies as a general partnership, the joint venture partners are jointly and severally liable for all of the obligations of the joint venture including obligations owed to the customer or any other person or entity. Quanta is not aware of circumstances that would lead to future claims against it for material amounts in connection with these joint and several liabilities. In the joint venture arrangements entered into by Quanta, each joint venturer indemnifies the other party for any liabilities incurred in excess of the liabilities such other party is obligated to bear under the respective joint venture agreement. It is possible, however, that Quanta could be required to pay or perform obligations in excess of its share if the other joint venturer failed or refused to pay or perform its share of the obligations. Quanta is not aware of circumstances that would lead to future claims against it for material amounts that would not be indemnified. As of September 30, 2013, Quanta had an outstanding capital commitment associated with its investment in HEP of $8.3 million which is expected to be paid in the fourth quarter of 2013. Additionally, Quanta has outstanding capital commitments associated with investments in unconsolidated affiliates related to planned midstream infrastructure projects of approximately $13.2 million as of September 30, 2013. Quanta is unable to determine the timing of these capital commitments but anticipates them to be paid before the end of 2015. Leases Quanta leases certain land, buildings and equipment under non-cancelable lease agreements, including related party leases. The terms of these agreements vary from lease to lease, including some with renewal options and escalation clauses. The following schedule shows the future minimum lease payments under these leases as of September 30, 2013 (in thousands):
|  | Operating Leases |
Year Ending December 31 — |  |  |  |
Remainder of 2013 |  | $ | 15,072 |
2014 |  |  | 39,299 |
2015 |  |  | 24,650 |
2016 |  |  | 18,411 |
2017 |  |  | 12,451 |
Thereafter |  |  | 22,689 |
Total minimum lease payments |  | $ | 132,572 |
Rent expense related to operating leases was approximately $28.5 million and $22.4 million for the three months ended September 30, 2013 and 2012 and approximately $80.2 million and $66.2 million for the nine months ended September 30, 2013 and 2012. Quanta has guaranteed the residual value on certain of its equipment operating leases. Quanta has agreed to pay any difference between this residual value and the fair market value of the underlying asset at the date of termination of the leases. At September 30, 2013, the maximum guaranteed residual value was approximately $278.4 million. Quanta believes that no significant payments will be made as a result of the difference between the fair market value of the leased equipment and the guaranteed residual value. However, there can be no assurance that significant payments will not be required in the future. Committed Capital Expenditures Quanta has committed capital for the expansion of its fiber optic network, although Quanta typically does not commit capital to new network expansions until it has a committed licensing arrangement in place with at least one customer. The amounts of committed capital expenditures are estimates of costs required to build the networks under contract. The actual capital expenditures related to building the networks could vary materially from these estimates. As of September 30, 2013, Quanta estimates these committed capital expenditures to be approximately $10.1 million for the period October 1, 2013 through December 31, 2013 and $17.7 million for 2014. Quanta also committed capital for the expansion of its vehicle fleet in order to accommodate manufacturer lead times on certain types of vehicles. As of September 30, 2013, production orders for approximately $9.6 million and $9.2 million had been issued with delivery dates occurring throughout 2013 and 2014. Although Quanta has committed to purchase these vehicles at the time of their delivery, Quanta intends that these orders will be assigned to third party leasing companies and made available to Quanta under certain of its master equipment lease agreements, thereby releasing Quanta from its capital expenditures commitment. Litigation and Claims Quanta is from time to time party to various lawsuits, claims and other legal proceedings that arise in the ordinary course of business. These actions typically seek, among other things, compensation for alleged personal injury, breach of contract and/or property damages, employment-related damages, punitive damages, civil penalties or other losses, or injunctive or declaratory relief. With respect to all such lawsuits, claims and proceedings, Quanta records a reserve when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. In addition, Quanta discloses matters for which management believes a material loss is at least reasonably possible. Except as otherwise stated below, none of these proceedings, separately or in the aggregate, are expected to have a material adverse effect on Quanta’s consolidated financial position, results of operations or cash flows. In all instances, management has assessed the matter based on current information and made a judgment concerning its potential outcome, giving due consideration to the nature of the claim, the amount and nature of damages sought and the probability of success. Management’s judgment may prove materially inaccurate, and such judgment is made subject to the known uncertainties of litigation. California Fire Claim — Amador County. In October 2004, a wildfire in Amador County, California, burned 16,800 acres. The United States Forest Service alleged that the fire originated as a result of the activities of a Quanta subsidiary crew performing vegetation management under a contract with Pacific Gas & Electric Co. (PG&E). In November 2007, the United States Department of Agriculture (USDA) sent a written demand to the Quanta subsidiary for payment of fire suppression costs of approximately $8.5 million. Quanta recorded a liability and corresponding insurance recovery receivable of approximately $8.5 million associated with this matter based on the written demand received from the USDA. The USDA informally communicated that it also intended to seek past and future restoration and other damages of approximately $51.3 million, as well as other unspecified damages. PG&E tendered defense and indemnification for the matter to Quanta in 2010. On August 3, 2012, the USDA filed suit in the United States District Court, Eastern District of California, against Quanta, its subsidiary and PG&E, seeking unspecified damages for fire suppression costs, rehabilitation and restoration expenses, and loss of timber, habitat and environmental values, among other things, including recovery of fees and expenses. During the first quarter of 2013, a settlement-in-principle was reached with the USDA, subject to approval by the United States Department of Justice, for an amount within Quanta’s available insurance coverages. The Department of Justice approved the settlement during the second quarter of 2013, and this matter has been concluded within Quanta's available insurance. National Gas Company of Trinidad and Tobago Arbitration. On October 1, 2010, Mears Group, Inc. (Mears), a wholly-owned subsidiary of Quanta, filed a request for arbitration with the International Chamber of Commerce (ICC) in London against the National Gas Company of Trinidad and Tobago (NGC). The request for arbitration arises out of a contract between Mears and NGC for horizontal directional drilling (HDD) services in connection with a shore approach of a natural gas pipeline. During pullback of the pipeline, a component on the drill rig operated by Mears failed, and the pipeline was lodged downhole. Subsequent efforts to salvage the pipeline by NGC, Mears and other parties failed to dislodge the pipeline. NGC subsequently hired a separate HDD contractor to complete reworks. Mears alleges breach of contract, among other things, and seeks recovery for works performed, standby costs, demobilization costs, and other expenses, totaling approximately $16.5 million, including taxes, and additionally seeks recovery of pre-judgment interest and attorneys’ fees and expenses. Mears contends in the arbitration that NGC breached the contract between the parties by providing a pipeline with insufficient buoyancy, weighing significantly more than the weight specified in the contract. In addition, Mears argues that NGC failed to provide a contractually required builders all-risk insurance policy naming Mears as an additional insured, which would have covered losses associated with a pullback failure. Moreover, Mears asserts that NGC agreed to indemnify Mears for losses to NGC’s equipment for events occurring during the project, and that any recovery by NGC is therefore barred. NGC counterclaimed in the arbitration, asserting that Mears breached the contract and performed negligently by failing to provide a drilling component capable of withstanding loads during pullback and providing a hole of insufficient cleanliness such that debris and other materials contributed to excess forces experienced during Mears’ pullback of the pipeline. NGC seeks recovery for the costs of the salvage operations, the cost of the reworks, as well as other costs, totaling approximately $79.5 million, and additionally seeks recovery of pre-judgment interest and attorneys’ fees and expenses. The arbitration hearings were completed during the third quarter of 2012, but no decision has been rendered. Mears also notified its insurers of the counterclaims, and although coverage was denied, Mears is continuing to pursue its insurers for coverage. Due to the nature of these claims, however, an adverse result in these proceedings could result in a significant uninsured loss that could have a material adverse effect on Quanta’s consolidated financial condition, results of operations and cash flows. Sunrise Powerlink Arbitration. On April 21, 2010, PAR, a wholly-owned subsidiary of Quanta, entered into a contract with SDG&E to construct a 117-mile electrical transmission line in Imperial and San Diego Counties, California, known as the Sunrise Powerlink project. Construction commenced on November 17, 2010, with commercial operations beginning on June 17, 2012, according to SDG&E. During the construction phase, SDG&E directed changes to the project construction schedule which required PAR to significantly increase its resources to the project in order to meet the customer required completion date. The project also experienced impacts beyond PAR’s control such as access delays and restrictions, as well as problems with customer supplied materials to the project. Since completion of the project, PAR and SDG&E have had ongoing meetings to review project scope, costs and performance criteria in order to reach resolution on the additional work performed and pricing of the change order under the contract, which has resulted in PAR and SDG&E being in agreement as to PAR’s direct costs. As of early October 2013, the parties were unsuccessful in agreeing on the final amount owed to PAR and as a result, recently agreed to proceed with a contractually agreed upon arbitration process, which commenced in the fourth quarter of 2013. Quanta believes that the amount which PAR is seeking will be affirmed in the arbitration process and that such amount will be entitled to statutory interest under California law at 10% per annum. Concentrations of Credit Risk Quanta is subject to concentrations of credit risk related primarily to its cash and cash equivalents and accounts receivable, including amounts related to unbilled accounts receivable and costs and estimated earnings in excess of billings on uncompleted contracts. Substantially all of Quanta’s cash investments are managed by what it believes to be high credit quality financial institutions. In accordance with Quanta’s investment policies, these institutions are authorized to invest this cash in a diversified portfolio of what Quanta believes to be high quality investments, which consist primarily of interest-bearing demand deposits, money market mutual funds and investment grade commercial paper with original maturities of three months or less. Although Quanta does not currently believe the principal amount of these investments is subject to any material risk of loss, changes in economic conditions could impact the interest income Quanta receives from these investments. In addition, Quanta grants credit under normal payment terms, generally without collateral, to its customers, which include electric power, natural gas and oil pipeline companies, governmental entities, general contractors, and builders, owners and managers of commercial and industrial properties located primarily in the United States and Canada. Consequently, Quanta is subject to potential credit risk related to changes in business and economic factors throughout the United States and Canada, which may be heightened as a result of uncertain economic and financial market conditions that have existed in recent years. However, Quanta generally has certain statutory lien rights with respect to services provided. Historically, some of Quanta’s customers have experienced significant financial difficulties, and others may experience financial difficulties in the future. These difficulties expose Quanta to increased risk related to collectability of billed and unbilled receivables and costs and estimated earnings in excess of billings on uncompleted contracts for services Quanta has performed. As of September 30, 2013, two customers accounted for approximately 13% and 10% of Quanta’s consolidated net position, which includes accounts receivable including long-term balances and costs and estimated earnings in excess of billings on uncompleted contracts less billings in excess of costs and unearned revenue. As of December 31, 2012, two customers accounted for approximately 16% and 11% of Quanta's consolidated net position. The services provided to these customers relate primarily to Quanta’s Electric Power Infrastructure Services segment. Substantially all of the balance for the customer with 10% of consolidated net position as of September 30, 2013 and 11% at December 31, 2012 relates to the Sunrise Powerlink project with a long-term receivable balance related to a significant change order that is subject to a contractually agreed upon arbitration process. During the third quarter of 2013, Quanta reclassified the receivable related to this matter from costs in excess of billings on uncompleted contracts to other assets, net due to the expected timetable for resolution of the matter. For additional information, see Litigation and Claims - Sunrise Powerlink Arbitration in this Note 10. Additionally, the customer with the 13% and 16% of consolidated net position at September 30, 2013 and December 31, 2012 also accounted for 10% of consolidated revenues for the nine months ended September 30, 2013. No other customers represented 10% or more of revenues for the three and nine months ended September 30, 2013 and 2012, and no other customers represented 10% or more of consolidated net position as of September 30, 2013 and December 31, 2012. Self-Insurance Quanta is insured for employer’s liability, general liability, auto liability and workers’ compensation claims. As of August 1, 2013, Quanta renewed its employer’s liability, general liability, auto liability and workers’ compensation policies for the current 2013 - 2014 policy year. As a result of the renewal, the deductibles for general liability and auto liability increased to $10.0 million per occurrence, while the deductible for workers’ compensation remained at $5.0 million per occurrence and the deductible for employer’s liability remained at $1.0 million per occurrence. Additionally, in connection with this renewal, the amount of letters of credit required by Quanta to secure its obligations under its casualty insurance programs, which is discussed further below, has increased. Between August 1, 2009 and July 31, 2013, all policy deductible levels were $5.0 million per occurrence, other than employer’s liability, which was subject to a deductible of $1.0 million. Quanta also has employee health care benefit plans for most employees not subject to collective bargaining agreements, of which the primary plan is subject to a deductible of $375,000 per claimant per year. Losses under all of these insurance programs are accrued based upon Quanta’s estimates of the ultimate liability for claims reported and an estimate of claims incurred but not reported, with assistance from third-party actuaries. These insurance liabilities are difficult to assess and estimate due to unknown factors, including the severity of an injury, the extent of damage, the determination of Quanta’s liability in proportion to other parties and the number of incidents not reported. The accruals are based upon known facts and historical trends, and management believes such accruals are adequate. As of September 30, 2013 and December 31, 2012, the gross amount accrued for insurance claims totaled $164.9 million and $160.8 million, with $122.9 million and $120.2 million considered to be long-term and included in other non-current liabilities. Related insurance recoveries/receivables as of September 30, 2013 and December 31, 2012 were $12.6 million and $22.2 million, of which $0.8 million and $2.3 million are included in prepaid expenses and other current assets and $11.8 million and $19.9 million are included in other assets, net. Quanta renews its insurance policies on an annual basis, and therefore deductibles and levels of insurance coverage may change in future periods. In addition, insurers may cancel Quanta’s coverage or determine to exclude certain items from coverage, or Quanta may elect not to obtain certain types or incremental levels of insurance if it believes that the cost to obtain such coverage exceeds the additional benefits obtained. In any such event, Quanta’s overall risk exposure would increase, which could negatively affect its results of operations, financial condition and cash flows. Letters of Credit Certain of Quanta’s vendors require letters of credit to ensure reimbursement for amounts they are disbursing on its behalf, such as to beneficiaries under its self-funded insurance programs. In addition, from time to time, certain customers require Quanta to post letters of credit to ensure payment to its subcontractors and vendors and to guarantee performance under its contracts. Such letters of credit are generally issued by a bank or similar financial institution, typically pursuant to Quanta’s credit facility. Each letter of credit commits the issuer to pay specified amounts to the holder of the letter of credit if the holder demonstrates that Quanta has failed to perform specified actions. If this were to occur, Quanta would be required to reimburse the issuer of the letter of credit. Depending on the circumstances of such a reimbursement, Quanta may also be required to record a charge to earnings for the reimbursement. Quanta does not believe that it is likely that any material claims will be made under a letter of credit in the foreseeable future. As of September 30, 2013, Quanta had $226.4 million in letters of credit outstanding under its credit facility primarily to secure obligations under its casualty insurance program. These are irrevocable stand-by letters of credit with maturities generally expiring at various times throughout 2013 and 2014. Upon maturity, it is expected that the majority of these letters of credit will be renewed for subsequent one-year periods. Performance Bonds and Parent Guarantees In certain circumstances, Quanta is required to provide performance bonds in connection with its contractual commitments. Quanta has indemnified its sureties for any expenses paid out under these performance bonds. As of September 30, 2013, the total amount of outstanding performance bonds was approximately $2.35 billion, and the estimated cost to complete these bonded projects was approximately $433.0 million. Quanta, from time to time, guarantees the obligations of its wholly owned subsidiaries, including obligations under certain contracts with customers, certain lease obligations and, in some states, obligations in connection with obtaining contractors’ licenses. Quanta is not aware of any material obligations for performance or payment asserted against it under any of these guarantees. Employment Agreements Quanta has various employment agreements with certain executives and other employees, which provide for compensation and certain other benefits and for severance payments under certain circumstances. Certain employment agreements also contain clauses that become effective upon a change of control of Quanta. Quanta may be obligated to pay certain amounts to such employees upon the occurrence of any of the defined events in the various employment agreements. Collective Bargaining Agreements Several of Quanta’s operating units are parties to various collective bargaining agreements with unions that represent certain of their employees. The collective bargaining agreements expire at various times and have typically been renegotiated and renewed on terms similar to those in the expiring agreements. The agreements require the operating units to pay specified wages, provide certain benefits to their union employees and contribute certain amounts to multi-employer pension plans and employee benefit trusts. Quanta’s multiemployer pension plan contribution rates generally are specified in the collective bargaining agreements (usually on an annual basis), and contributions are made to the plans on a “pay-as-you-go” basis based on its union employee payrolls, which cannot be determined for future periods because the location and number of union employees that Quanta employs at any given time and the plans in which they may participate vary depending on the projects Quanta has ongoing at any time and the need for union resources in connection with those projects. The Pension Protection Act of 2006 (PPA) also added special funding and operational rules generally applicable to plan years beginning after 2007 for multi-employer plans that are classified as “endangered,” “seriously endangered” or “critical” status based on multiple factors (including, for example, the plan’s funded percentage, cash flow position and whether it is projected to experience a minimum funding deficiency). Plans in these classifications must adopt measures to improve their funded status through a funding improvement or rehabilitation plan, as applicable, which may require additional contributions from employers (which may take the form of a surcharge on benefit contributions) and/or modifications to retiree benefits. Certain plans to which Quanta contributes or may contribute in the future are in “endangered,” “seriously endangered” or “critical” status. The amount of additional funds, if any, that Quanta may be obligated to contribute to these plans in the future cannot be estimated due to uncertainty of the future levels of work that require the specific use of union employees covered by these plans, as well as the future contribution levels and possible surcharges on contributions applicable to these plans. Quanta may be subject to additional liabilities imposed by law as a result of its participation in multi-employer defined benefit pension plans. For example, the Employee Retirement Income Security Act of 1974, as amended by the Multi-Employer Pension Plan Amendments Act of 1980, imposes certain liabilities upon an employer who is a contributor to a multi-employer pension plan if the employer withdraws from the plan or the plan is terminated or experiences a mass withdrawal. These liabilities include an allocable share of the unfunded vested benefits in the plan for all plan participants, not merely the benefits payable to a contributing employer’s own retirees. As a result, participating employers may bear a higher proportion of liability for unfunded vested benefits if other participating employers cease to contribute or withdraw, with the reallocation of liability being more acute in cases when a withdrawn employer is insolvent or otherwise fails to pay its withdrawal liability. Other than as described below, Quanta is not aware of any material amounts of withdrawal liability that have been incurred as a result of a withdrawal by any of Quanta’s operating units from any multi-employer defined benefit pension plans. In the fourth quarter of 2011, Quanta recorded a partial withdrawal liability of approximately $32.6 million related to the withdrawal by certain Quanta subsidiaries from the Central States, Southeast and Southwest Areas Pension Plan (the Central States Plan). The partial withdrawal liability recognized by Quanta was based on estimates received from the Central States Plan during 2011 for a complete withdrawal by all Quanta companies participating in the Central States Plan. The withdrawal followed an amendment to a collective bargaining agreement with the International Brotherhood of Teamsters that eliminated obligations to contribute to the Central States Plan, which is in critical status and is significantly underfunded as to its vested benefit obligations. The amendment was negotiated by the Pipe Line Contractors Association (PLCA) on behalf of its members, which include the Quanta subsidiaries that withdrew from the Central States Plan. Quanta believed that withdrawing from the Central States Plan in the fourth quarter of 2011 was advantageous because it limited Quanta’s exposure to increased liabilities from a future withdrawal if the underfunded status of the Central States Plan deteriorates further. Quanta and other PLCA members now contribute to a different multi-employer pension plan on behalf of Teamsters employees. The Central States Plan has asserted that the withdrawal of the PLCA members was not effective in 2011, although Quanta believes that a legally effective withdrawal occurred in the fourth quarter of 2011. During the third quarter of 2012, the Central States Plan provided Quanta with an estimate of the potential withdrawal liability, indicating that the withdrawal liability is approximately $32.8 million based on a partial withdrawal in the fourth quarter of 2011, approximately $39.7 million based on a partial withdrawal in the first quarter of 2012, or approximately $40.1 million based on a complete withdrawal in 2012. Certain other Quanta subsidiaries continued participation in the Central States Plan, and Quanta subsequently effected a complete withdrawal as of December 31, 2012. The consequences of the complete withdrawal of Quanta’s subsidiaries from the plan will depend on various factors, including interpretations of the terms of the collective bargaining agreements under which the subsidiaries participated and whether exemptions from withdrawal liability applicable to construction industry employers will be available. Based on the previous estimate of liability associated with a complete withdrawal from the Central States Plan, and allowing for the exclusion of amounts believed by management to have been improperly included in such estimate, Quanta will seek to challenge and further negotiate the amount owed in connection with this matter. Given the unknown nature of some of these factors, the final withdrawal liability cannot yet be determined with certainty; therefore the ultimate amount owed upon final settlement of these matters could be materially higher than the $32.6 million Quanta recognized in the fourth quarter of 2011. Indemnities Quanta generally indemnifies its customers for the services it provides under its contracts, as well as other specified liabilities, which may subject Quanta to indemnity claims and liabilities and related litigation. Quanta has also indemnified various parties against specified liabilities that those parties might incur in the future in connection with Quanta’s previous acquisition or disposition of certain companies. The indemnities under acquisition or disposition agreements are usually contingent upon the other party incurring liabilities that reach specified thresholds. As of September 30, 2013, except as otherwise set forth above in Litigation and Claims, Quanta does not believe any material liabilities for asserted claims exist against it in connection with any of these indemnity obligations.

X
- Details
Name: | us-gaap_CommitmentsAndContingenciesDisclosureAbstract
Namespace Prefix: | us-gaap_
Data Type: | xbrli:stringItemType
Balance Type: | na
Period Type: | duration

X
- Definition The entire disclosure for commitments and contingencies. + References Reference 1: http://www.xbrl.org/2003/role/presentationRef -Publisher FASB -Name Accounting Standards Codification -Topic 210 -SubTopic 10 -Section S99 -Paragraph 1 -Subparagraph (SX 210.5-02.25) -URI http://asc.fasb.org/extlink&oid=6877327&loc=d3e13212-122682 Reference 2: http://www.xbrl.org/2003/role/presentationRef -Publisher FASB -Name Accounting Standards Codification -Topic 825 -SubTopic 20 -Section 50 -Paragraph 1 -URI http://asc.fasb.org/extlink&oid=6449706&loc=d3e16207-108621 Reference 3: http://www.xbrl.org/2003/role/presentationRef -Publisher FASB -Name Accounting Standards Codification -Topic 460 -SubTopic 10 -Section 50 -Paragraph 8 -URI http://asc.fasb.org/extlink&oid=6398077&loc=d3e12565-110249 Reference 4: http://www.xbrl.org/2003/role/presentationRef -Publisher FASB -Name Accounting Standards Codification -Topic 450 -SubTopic 20 -Section 50 -Paragraph 4 -URI http://asc.fasb.org/extlink&oid=25496072&loc=d3e14435-108349 Reference 5: http://www.xbrl.org/2003/role/presentationRef -Publisher FASB -Name Accounting Standards Codification -Topic 440 -SubTopic 10 -Section 50 -Paragraph 2 -URI http://asc.fasb.org/extlink&oid=6394976&loc=d3e25287-109308 + Details
Name: | us-gaap_CommitmentsAndContingenciesDisclosureTextBlock
Namespace Prefix: | us-gaap_
Data Type: | nonnum:textBlockItemType
Balance Type: | na
Period Type: | duration