XML 39 R25.htm IDEA: XBRL DOCUMENT
v3.22.4

Commitments and Contingencies | 12 Months Ended
--- | ---
Dec. 31, 2022
Commitments and Contingencies Disclosure [Abstract] |
Commitments and Contingencies | COMMITMENTS AND CONTINGENCIES: Legal Proceedings Quanta is from time to time party to various lawsuits, claims and other legal proceedings that arise in the ordinary course of business. These actions typically seek, among other things, compensation for alleged personal injury, property damage, breach of contract, negligence or gross negligence, environmental liabilities, wage and hour and other employment-related damages, punitive damages, consequential damages, civil penalties or other losses, or injunctive or declaratory relief. With respect to all such lawsuits, claims and proceedings, Quanta records a reserve when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. In addition, Quanta discloses matters for which management believes a material loss is at least reasonably possible. The assessment of whether a loss is probable or reasonably possible, and whether the loss or a range of loss is estimable, often involves a series of complex judgments about future events. In all instances, management has assessed the matter based on current information and made a judgment concerning its potential outcome, giving due consideration to the nature of the claim, the amount and nature of damages sought and the probability of success and taking into account, among other things, negotiations with claimants, discovery, settlements and payments, judicial rulings, arbitration and mediation decisions, advice of internal and external legal counsel, and other information and events pertaining to a particular matter. Costs incurred for litigation are expensed as incurred. Except as otherwise stated below, none of these proceedings are expected to have a material adverse effect on Quanta’s consolidated financial position, results of operations or cash flows. However, management’s judgment may prove materially inaccurate, and such judgment is made subject to the known uncertainties of litigation. Peru Project Dispute In 2015, Redes Andinas de Comunicaciones S.R.L. (Redes), a majority-owned subsidiary of Quanta, entered into two separate contracts with an agency of the Peruvian Ministry of Transportation and Communications (MTC), currently Programa Nacional de Telecomunicaciones (PRONATEL), as successor to Fondo de Inversion en Telecomunicaciones (FITEL), pursuant to which Redes would design, construct and operate certain telecommunication networks in rural regions of Peru. The aggregate consideration provided for in the contracts was approximately $248 million, consisting of approximately $151 million to be paid during the construction period and approximately $97 million to be paid during a 10-year post-construction operation and maintenance period. At the beginning of the project, FITEL made advance payments totaling approximately $87 million to Redes, which were secured by two on-demand advance payment bonds posted by Redes to guarantee proper use of the payments in the execution of the project. Redes also provided two on-demand performance bonds in the aggregate amount of $25 million to secure performance of its obligations under the contracts. During the construction phase, the project experienced numerous challenges and delays, primarily related to issues which Quanta believes were outside of the control of and not attributable to Redes, including, among others, weather-related issues, local opposition to the project, permitting delays, the inability to acquire clear title to certain required parcels of land and other delays which Quanta believes were attributable to FITEL/PRONATEL. In response to various of these challenges and delays, Redes requested and received multiple extensions to certain contractual deadlines and relief from related liquidated damages. However, in April 2019, PRONATEL provided notice to Redes claiming that Redes was in default under the contracts due to the delays and that PRONATEL would terminate the contracts if the alleged defaults were not cured. Redes responded by claiming that it was not in default, as the delays were due to events not attributable to Redes, and therefore PRONATEL was not entitled to terminate the contracts. PRONATEL subsequently terminated the contracts for alleged cause prior to completion of Redes’ scope of work, exercised the on-demand performance bonds and advance payment bonds against Redes, and indicated its intention to claim damages, including liquidated damages under the contracts. As of the date of the contract terminations, Redes had incurred costs of approximately $157 million related to the design and construction of the project and had received approximately $100 million of payments (inclusive of the approximately $87 million advance payments). In May 2019, Redes filed for arbitration before the Court of International Arbitration of the International Chamber of Commerce (ICC) against PRONATEL and the MTC. In the arbitration, Redes claimed that PRONATEL: breached and wrongfully terminated the contracts; wrongfully executed the advance payment bonds and the performance bonds; and was not entitled to the alleged amount of liquidated damages, and sought compensation for various damages arising from PRONATEL’s actions in the initially claimed amount of approximately $190 million. In August 2022, Redes received the decision of the arbitration tribunal, which unanimously found in favor of Redes in connection with its claims and ordered, among other things, (i) repayment of the amounts collected by PRONATEL under the advance payment bonds and the performance bonds; (ii) payment of amounts owed for work completed by Redes under the contracts; (iii) payment of lost income in connection with Redes’ future operation and maintenance of the networks; and (iv) payment of other related costs and damages to Redes as a result of the breach and improper termination of the contracts (including costs related to the execution of the bonds, costs related to the transfer of the networks and legal and expert fees). Accordingly, the arbitration tribunal awarded Redes approximately $177 million. In addition, per the terms of the arbitration decision, interest will accrue on the amount owed up to the date of payment. The decision of the arbitration tribunal is final; however, there are limited grounds on which PRONATEL and the MTC may seek to annul the decision in Peruvian court, and in December 2022, an annulment proceeding was filed by PRONATEL and the MTC. Additionally, following the favorable arbitration ruling, in December 2022 Quanta received $100.5 million pursuant to coverage under an insurance policy for the improper collection by PRONATEL and the MTC of the advance payment and performance bonds, and in January 2023 Quanta received $6.8 million pursuant to coverage under an insurance policy for nonpayment by PRONATEL and the MTC of amounts owed for work completed by Redes. Quanta is continuing to pursue collection of the ICC arbitration award and any amount collected would result in repayment of an equal amount to the insurers up to the amount received from the insurers. As a result, $100.5 million is included in “Insurance and other non-current liabilities” in the accompanying consolidated balance sheet as of December 31, 2022. Quanta also reserves the right to seek full compensation for the loss of its investment under applicable legal regimes, including investment treaties and customary international law, as well as to seek resolution through direct discussions with PRONATEL or the MTC. In connection with these rights, in May 2020 Quanta’s Dutch subsidiary delivered to the Peruvian government an official notice of dispute arising from the termination of the contracts and related acts by PRONATEL (which are attributable to Peru) under the Agreement on the Encouragement and Reciprocal Protection of Investments between the Kingdom of the Netherlands and the Republic of Peru (Investment Treaty). The Investment Treaty protects Quanta’s subsidiary’s indirect ownership stake in Redes and the project, and provides for rights and remedies distinct from the ICC arbitration. In December 2020, Quanta’s Dutch subsidiary filed a request for the institution of an arbitration proceeding against Peru with the International Centre for Settlement of Investment Disputes (ICSID) related to Peru’s breach of the Investment Treaty, which was registered by ICSID in January 2021. In the ICSID arbitration, Quanta’s Dutch subsidiary claims, without limitation, that Peru: (i) treated the subsidiary’s investment in Redes and the project unfairly and inequitably; and (ii) effectively expropriated the subsidiary’s investment in Redes and the project. In addition, Quanta’s Dutch subsidiary is seeking full compensation for all damages arising from Peru’s actions, including but not limited to (i) the fair market value of the investment and/or lost profits; (ii) attorneys’ fees and arbitration costs; (iii) other related costs and damages and (iv) pre- and post-award interest. The ICSID arbitration hearing is currently scheduled to occur in June 2023. Quanta believes Redes is entitled to all amounts awarded by the ICC arbitration tribunal, and that its Dutch subsidiary is entitled to other amounts associated with the pending ICSID arbitration proceeding. Quanta and Redes intend to vigorously pursue recovery of the amounts awarded by the ICC arbitration tribunal and take additional legal actions deemed necessary to enforce the ICC arbitration decision. However, due to the inherent uncertainty involved with, among other things, the annulment proceeding, the ultimate timing and conclusion with respect to collection of the amount of the ICC arbitration award remains unknown. As a result of the contract terminations and the inherent uncertainty involved in arbitration proceedings and recovery of amounts owed, during the three months ended June 30, 2019, Quanta recorded a charge to earnings of $79.2 million, which included a reduction of previously recognized earnings on the project, a reserve against a portion of the project costs incurred through the project termination date, an accrual for a portion of the alleged liquidated damages, and the estimated costs to complete the project turnover and close out the project. Quanta also initially recorded a contract receivable of approximately $120 million related to the project during the three months ended June 30, 2019, which includes the amounts collected by PRONATEL through exercise of the advance payment bonds and performance bonds, and that receivable was not changed as of December 31, 2021 and 2022 and is included in “Other assets, net” in the accompanying consolidated balance sheet. After considering, as discussed above, that the ultimate timing and conclusion with respect to collection of the ICC arbitration award remains unknown, Quanta has not recognized a gain in the current period. To the extent amounts in excess of the current receivable are determined to be realizable, a gain would be recorded in the period such determination is made. However, if Quanta is ultimately not successful with respect to collection of the ICC arbitration award, through annulment or otherwise, or with respect to its claims in the pending ICSID arbitration proceeding, this matter could result in an additional significant loss that could have a material adverse effect on Quanta’s consolidated results of operations and cash flows. Lorenzo Benton v. Telecom Network Specialists, Inc., et al. In June 2006, plaintiff Lorenzo Benton filed a class action complaint in the Superior Court of California, County of Los Angeles, alleging various wage and hour violations against Telecom Network Specialists (TNS), a former subsidiary of Quanta. Quanta retained liability associated with this matter pursuant to the terms of Quanta’s sale of TNS in December 2012. Benton represents a class of workers that includes all persons who worked on certain TNS projects, including individuals that TNS retained through numerous staffing agencies. The plaintiff class in this matter is seeking damages for unpaid wages, penalties associated with the failure to provide meal and rest periods and overtime wages, interest and attorneys’ fees. In January 2017, the trial court granted a summary judgment motion filed by the plaintiff class and found that TNS was a joint employer of the class members and that it failed to provide adequate meal and rest breaks and failed to pay overtime wages. During 2019 and 2020, the parties filed additional summary judgment and other motions and a bench trial on liability and damages was held. Liability and damages have been determined by the trial court, with the amount of liability for TNS, including interest through the date of the trial court’s orders, determined to be approximately $9.5 million. Separately, in 2022, the court issued a final ruling awarding attorneys’ fees and costs to plaintiffs in the amount of approximately $17.3 million. Quanta continues to contest its liability and the damages calculations asserted by the plaintiff class in this matter and believes the court’s decisions on these matters are not supported by controlling law and that attorneys’ fees would only be recoverable by the plaintiff class in the event Quanta’s appeal of the trial court’s rulings on liability and damages is unsuccessful. Additionally, in November 2007, TNS filed cross complaints for indemnity and breach of contract against the staffing agencies, which employed many of the individuals in question. In December 2012, the trial court heard cross-motions for summary judgment filed by TNS and the staffing agencies pertaining to TNS’s demand for indemnity. The court denied TNS’s motion and granted the motions filed by the staffing agencies; however, the California Appellate Court reversed the trial court’s decision in part and instructed the trial court to reconsider its ruling. In February 2017, the court denied a new motion for summary judgment filed by the staffing companies and has since stated that the staffing companies would be liable to TNS for any damages owed to the class members that the staffing companies employed. However, Quanta currently believes that, due to solvency issues, any contribution from the staffing companies may not be substantial. The final amount of liability and attorneys’ fees, if any, payable in connection with this matter remains the subject of pending litigation and will ultimately depend on various factors, including the outcome of the parties’ appeals of the trial court’s rulings on liability, damages, and attorneys’ fees and costs, and the solvency of the staffing agencies. Based on review and analysis of the trial court’s rulings on liability, Quanta does not believe, at this time, that it is probable this matter will result in a material loss. However, if Quanta is unsuccessful in this litigation and the staffing agencies are unable to fund damages owed to class members, based on rulings issued by the trial court, Quanta believes the range of reasonably possible loss to Quanta upon final resolution of this matter could be up to approximately $26.8 million, plus any additional attorneys’ fees, interest, and expenses awarded to the plaintiff class. Hallen Acquisition Assumed Liability In August 2019, in connection with the acquisition of The Hallen Construction Co., Inc. (Hallen), Quanta assumed certain contingent liabilities associated with a March 2014 natural gas-fed explosion and fire in the Manhattan borough of New York City, New York. The incident resulted in, among other things, loss of life, personal injury and the destruction of two buildings and other property damage. After investigation, the National Transportation Safety Board determined that the probable cause of the incident was the failure of certain natural gas infrastructure installed by Consolidated Edison, Inc. (Con Ed) and the failure of certain sewer infrastructure maintained by the City of New York. Pursuant to a contract with Con Ed, Hallen had performed certain work related to such natural gas infrastructure and agreed to indemnify Con Ed for certain claims, liabilities and costs associated with its work. Numerous lawsuits are pending in New York state courts related to the incident, which generally name Con Ed, the City of New York and Hallen as defendants. These lawsuits are at various stages and generally seek unspecified damages and, in some cases, punitive damages, for wrongful death, personal injury, property damage and business interruption. As of December 31, 2022, Quanta had not recorded an accrual related to this matter. Hallen’s liabilities associated with this matter are expected to be covered under applicable insurance policies or contractual remedies negotiated by Quanta with the former owners of Hallen. If a loss becomes probable and estimable with respect to this matter, Quanta expects to accrue its estimated liability and a receivable in the same amount. However, the ultimate amount of liability in connection with this matter remains subject to uncertainties associated with pending litigation, including, among other things, the apportionment of liability among the defendants and other responsible parties and the likelihood and amount of potential damages claims. As a result, this matter could result in a loss that is in excess of, or not covered by, such insurance or contractual remedies, which could have a material adverse effect on Quanta’s consolidated financial condition, results of operations and cash flows. Silverado Wildfire Matter During 2022 and 2023, two of Quanta’s subsidiaries received tenders of defense and demands for preservation of evidence from Southern California Edison Company (SCE) related to lawsuits filed from April 2021 through January 2023 against SCE and T-Mobile USA, Inc. (T-Mobile) in the Superior Court of California, County of Orange. The lawsuits generally assert property damage and related claims on behalf of certain individuals and subrogation claims on behalf of insurers relating to damages caused by a wildfire that began in October 2020 in Orange County, California (the Silverado Fire) and that is purported to have damaged approximately 13,000 acres. The lawsuits allege the Silverado Fire originated from utility poles in the area, generally claiming that each defendant failed to adequately maintain, inspect, repair or replace its overhead facilities, equipment and utility poles and remove vegetation in the vicinity; that the utility poles were overloaded with equipment from shared usage; and that SCE failed to de-energize its facilities during red flag warnings for a Santa Ana wind event. The lawsuits allege the Silverado Fire started when SCE and T-Mobile equipment contacted each other and note the Orange County Fire Department is investigating whether a T-Mobile lashing wire contacted an SCE overhead primary conductor in high winds. T-Mobile has filed cross-complaints against SCE alleging, among other things, that the ignition site of the Silverado Fire encompassed two utility poles replaced by SCE or a third party engaged by SCE, and that certain equipment, including T-Mobile’s lashing wire, was not sufficiently re-secured after the utility pole replacements. One of Quanta’s subsidiaries performed planning and other services related to the two utility poles, and another Quanta subsidiary replaced the utility poles and reattached the electrical and telecommunication equipment to the new utility poles in March 2019, approximately 19 months before the Silverado Fire. Pursuant to the general terms of a master services agreement and a master consulting services agreement between the Quanta subsidiaries and SCE, the subsidiaries agreed to defend and indemnify SCE against certain claims arising with respect to performance or nonperformance under the agreements. The SCE tender letters seek contractual indemnification and defense from Quanta’s subsidiaries for the claims asserted against SCE in the lawsuits and the T-Mobile cross-complaints. Quanta’s subsidiaries intend to vigorously defend against the lawsuits, the T-Mobile cross-complaints and any other claims asserted in connection with the Silverado Fire. Quanta will continue to review additional information in connection with this matter as litigation and resolution efforts progress, and any such information may potentially allow Quanta to determine an estimate of potential loss, if any. As of December 31, 2022, Quanta had not recorded an accrual with respect to this matter, and Quanta is currently unable to reasonably estimate a range of reasonably possible loss, if any, because there are a number of unknown facts and legal considerations that may impact the amount of any potential liability. Quanta also believes that to the extent its subsidiaries are determined to be liable for any damages resulting from this matter, its insurance would be applied to any such liabilities over its deductible amount and its insurance coverage would be adequate to cover such potential liabilities. However, the ultimate amount of any potential liability and insurance coverage in connection with this matter remains subject to uncertainties associated with pending and potential future litigation. Concentrations of Credit Risk Quanta is subject to concentrations of credit risk related primarily to its cash and cash equivalents and its net receivable position with customers, which includes amounts related to billed and unbilled accounts receivable and contract assets for services Quanta has performed for customers. Substantially all of Quanta’s cash and cash equivalents are managed by what it believes to be high credit quality financial institutions. In accordance with Quanta’s investment policies, these institutions are authorized to invest cash and cash equivalents in a diversified portfolio of what Quanta believes to be high quality cash and cash equivalent investments, which consist primarily of interest-bearing demand deposits, money market investments and money market mutual funds. Although Quanta does not currently believe the principal amount of these cash and cash equivalents is subject to any material risk of loss, changes in economic conditions could impact the interest income Quanta receives from these investments. Quanta grants credit under normal payment terms, generally without collateral, to its customers, which primarily include utilities, renewable energy developers, communications providers, industrial companies and energy delivery companies located primarily in the United States, Canada and Australia. While Quanta generally has certain statutory lien rights with respect to services provided, Quanta is subject to potential credit risk related to business, economic and financial market conditions that affect these customers and locations, which has been heightened as a result of recent economic and financial market conditions, including in connection with the uncertainties and challenges in the overall economy, including, among other things, inflationary pressure and increased interest rates. Some of Quanta’s customers have experienced significant financial difficulties (including bankruptcy), and customers may experience financial difficulties in the future. These difficulties expose Quanta to increased risk related to collectability of billed and unbilled receivables and contract assets for services Quanta has performed. See Note 4 for additional discussion on concentrations on credit risk. Insurance As discussed in Note 2, Quanta carries various insurance policies. As of December 31, 2022 and 2021, the gross amount accrued for employer’s liability, workers’ compensation, auto liability, general liability and group health claims totaled $319.6 million and $318.2 million, respectively, of which $209.8 million and $238.0 million are included in “Insurance and other non-current liabilities”, and the remainder is included in “Accounts payables and accrued expenses.” Related insurance recoveries/receivables as of December 31, 2022 and 2021 were $5.8 million and $28.6 million, respectively, of which $0.3 million and $0.4 million are included in “Prepaid expenses and other current assets” and $5.5 million and $28.2 million are included in “Other assets, net.” Quanta renews its insurance policies on an annual basis, and therefore deductibles and levels of insurance coverage may change in future periods. In addition, insurers may cancel Quanta’s coverage or determine to exclude certain items from coverage, including wildfires, or Quanta may elect not to obtain certain types or incremental levels of insurance based on the potential benefits considered relative to the cost of such insurance, or coverage may not be available at reasonable and competitive rates. Letters of Credit Certain of Quanta’s vendors require letters of credit to ensure reimbursement for amounts they are disbursing on Quanta’s behalf, such as to beneficiaries under its insurance programs. In addition, from time to time, certain customers require Quanta to post letters of credit to ensure payment of subcontractors and vendors and guarantee performance under contracts. Such letters of credit are generally issued by a bank or similar financial institution, typically pursuant to Quanta’s senior credit facility. Each letter of credit commits the issuer to pay specified amounts to the holder of the letter of credit if the holder claims that Quanta has failed to perform specified actions. If this were to occur, Quanta would be required to reimburse the issuer of the letter of credit. Depending on the circumstances of such a reimbursement, Quanta may also be required to record a charge to earnings for the reimbursement. See Note 10 for additional information regarding Quanta’s letters of credit outstanding. Quanta is not aware of any claims currently asserted or threatened under any of these letters of credit that are material, individually or in the aggregate. However, to the extent payment is required for any such claims, the amount paid could be material and could adversely affect Quanta’s consolidated business, financial condition, results of operations and cash flows. Bonds and Parent Guarantees Many customers, particularly in connection with new construction, require Quanta to post performance and payment bonds. These bonds provide a guarantee that Quanta will perform under the terms of a contract and pay its subcontractors and vendors. In certain circumstances, the customer may demand that the surety make payments or provide services under the bond, and Quanta must reimburse the surety for any expenses or outlays it incurs. Quanta may also be required to post letters of credit in favor of the sureties, which would reduce the borrowing availability under its senior credit facility. Quanta has not been required to make any material reimbursements to its sureties for bond-related costs except as described in Legal Proceedings - Peru Project Dispute above. However, to the extent further reimbursements are required, the amounts could be material and could adversely affect Quanta’s consolidated business, financial condition, results of operations and cash flows. As of December 31, 2022, Quanta is not aware of any outstanding material obligations for payments related to bond obligations. Performance bonds expire at various times ranging from mechanical completion of a project to a period extending beyond contract completion in certain circumstances, and therefore a determination of maximum potential amounts outstanding requires certain estimates and assumptions. Such amounts can also fluctuate from period to period based upon the mix and level of Quanta’s bonded operating activity. As of December 31, 2022, the estimated total amount of the outstanding performance bonds was estimated to be approximately $4.5 billion. Quanta’s estimated maximum exposure related to the value of the performance bonds outstanding is lowered on each bonded project as the cost to complete is reduced, and each commitment under a performance bond generally extinguishes concurrently with the expiration of its related contractual obligation. The estimated cost to complete these bonded projects was approximately $1.2 billion as of December 31, 2022. Additionally, from time to time, Quanta guarantees certain obligations and liabilities of its subsidiaries that may arise in connection with, among other things, contracts with customers, equipment lease obligations, joint venture arrangements and contractor licenses. These guarantees may cover all of the subsidiary’s unperformed, undischarged and unreleased obligations and liabilities under or in connection with the relevant agreement. For example, with respect to customer contracts, a guarantee may cover a variety of obligations and liabilities arising during the ordinary course of the subsidiary’s business or operations, including, among other things, warranty and breach of contract claims, third party and environmental liabilities arising from the subsidiary’s work and for which it is responsible, liquidated damages, or indemnity claims. Quanta is not aware of any claims under any guarantees that are material. To the extent a subsidiary incurs a material obligation or liability and Quanta has guaranteed the performance or payment of such obligation or liability, the recovery by a customer or other counterparty or a third party will not be limited to the assets of the subsidiary. As a result, responsibility under the guarantee could exceed the amount recoverable from the subsidiary alone and could materially and adversely affect Quanta’s consolidated business, financial condition, results of operations and cash flows. Collective Bargaining Agreements and Multiemployer Pension Plans Certain of Quanta’s operating companies are parties to collective bargaining agreements with unions that represent certain of their employees. The collective bargaining agreements expire at various times and have typically been renegotiated and renewed on terms similar to those in the expiring agreements. From time to time, Quanta is a party to grievance and arbitration actions based on claims arising out of the collective bargaining agreements. The agreements require the operating companies to pay specified wages, provide certain benefits to union employees and contribute certain amounts to multiemployer pension plans and employee benefit trusts. Quanta’s multiemployer pension plan contribution rates generally are made to the plans on a “pay-as-you-go” basis based on its union employee payrolls. The location and number of union employees that Quanta employs at any given time and the plans in which they may participate vary depending on Quanta’s need for union resources in connection with its ongoing projects. Therefore, Quanta is unable to accurately predict its union employee payroll and the resulting multiemployer pension plan contribution obligations for future periods. In addition, Quanta may also be subject to liabilities as a result of its participation in, or withdrawal from, multiemployer defined benefit pension plans. Quanta may be required to make additional contributions to its multiemployer pension plans if they become underfunded, and these additional contributions will be determined based on Quanta’s union employee payrolls. Certain plans to which Quanta contributes or may contribute in the future may adopt measures to improve their funded status through a funding improvement or rehabilitation plan, as applicable, which may require additional contributions from employers (e.g., a surcharge on benefit contributions) and/or modifications to retiree benefits. The amount, if any, that Quanta may be obligated to contribute to these plans cannot be reasonably estimated due to uncertainty regarding the amount of future work involving covered union employees, future contribution levels and possible surcharges on plan contributions. Quanta may also be subject to additional liabilities imposed by law if it or another participating employer withdraws from a multiemployer defined benefit pension plan, a plan is terminated or a plan experiences a mass withdrawal. These liabilities may include an allocable share of the unfunded vested benefits in the plan for all plan participants, not only the benefits payable to a contributing employer’s own retirees. As a result, participating employers may bear a higher proportion of liability for unfunded vested benefits if other participating employers cease to contribute or withdraw, with the reallocation of liability being more acute in cases when a withdrawn employer is insolvent or otherwise fails to pay its withdrawal liability. Quanta is not aware of any material withdrawal liabilities that have been incurred or asserted and that remain outstanding as a result of a withdrawal by Quanta from a multiemployer defined benefit pension plan. However, Quanta’s future contribution obligations and potential withdrawal liability exposure could vary based on the investment and actuarial performance of the multiemployer pension plans to which it contributes and other factors, which could be negatively impacted as a result of recent unfavorable and uncertain economic and financial market conditions. Quanta has been subject to significant withdrawal liabilities in the past, and to the extent Quanta is subject to material withdrawal liabilities in the future, such liability could adversely affect its business, financial condition, results of operations and cash flows. Indemnities Quanta generally indemnifies its customers for the services it provides under its contracts and other specified liabilities, which may subject Quanta to indemnity claims and liabilities and related litigation. Quanta is not aware of any indemnity claims in connection with these obligations that are material, except as described in Legal Proceedings - Silverado Wildfire Matter above. Additionally, in the normal course of Quanta’s acquisition transactions, Quanta has granted indemnification rights to various parties against certain potential liabilities related to the transaction or the acquired business and obtained rights to indemnification from the sellers or former owners of acquired businesses for certain risks, liabilities and obligations arising from business operations prior to the date of acquisition, such as financial, performance, operational, safety, workforce, environmental, litigation, compliance or tax issues, some of which Quanta may not have discovered during due diligence. However, the indemnities may not cover all of Quanta’s exposure for such pre-acquisition matters, or the indemnitors may be unwilling or unable to pay amounts owed to Quanta. Accordingly, Quanta may incur expenses for which it is not reimbursed, and such amounts could be material and could have a material adverse effect on Quanta’s business or consolidated financial condition, results of operations and cash flows. For example, Quanta has obtained certain indemnification rights from the former owners of Hallen with respect to contingent liabilities that were assumed in connection with the acquisition, as described in Legal Proceedings — Hallen Acquisition Assumed Liability above. Joint Venture Liabilities As described in Notes 2, 8 and 13, Quanta is a participant in certain joint ventures, including joint venture entities that provide infrastructure-related services under specific customer contracts and partially owned entities that own, operate and/or maintain certain infrastructure assets. If losses are incurred by joint venture entities in which Quanta holds an interest, they are generally shared ratably based on the percentage ownership of the participants in the structures. However, in Quanta’s joint venture structures that provide infrastructure-related services, each participant is typically jointly and severally liable for all of the obligations of the joint venture entity pursuant to the contract with the customer, and therefore Quanta can be liable for full performance of the contract with the customer. Additionally, in circumstances where Quanta’s participation in a joint venture qualifies as a general partnership, Quanta can be liable for all obligations of the joint venture, including obligations owed to the customer or any other person or entity. Quanta is not aware of circumstances that would lead to future claims against it for material amounts in connection with these liabilities. Additionally, typically each joint venture participant agrees to indemnify the other participant for any liabilities incurred in excess of what the other participant is obligated to bear under the respective joint venture agreement or in accordance with the scope of work subcontracted to each participant. It is possible, however, that Quanta could be required to pay or perform obligations in excess of its share if another participant is unable or refuses to pay or perform its share of the obligations. Quanta is not aware of circumstances that would lead to future claims against it for material amounts that would not be indemnified. However, to the extent any such claims arise, they could be material and could adversely affect Quanta’s consolidated business, financial condition, results of operations and cash flows. Capital Commitments and Other Committed Expenditures As of December 31, 2022, Quanta had $0.6 million of outstanding capital commitments associated with investments in unconsolidated affiliates payable by December 31, 2023 and $10.5 million payable thereafter. Quanta has capital commitments for the expansion of its equipment fleet in order to accommodate manufacturer lead times on certain types of vehicles. As of December 31, 2022, Quanta had $172.3 million of production orders with expected delivery dates in 2023. Although Quanta has committed to purchase these vehicles at the time of their delivery, Quanta anticipates that the majority of these orders will be assigned to third-party leasing companies and made available under certain master equipment lease agreements, thereby releasing Quanta from its capital commitments. Employment Agreements Quanta has various employment agreements with certain executives and other employees, which provide for compensation, other benefits and, under certain circumstances, severance payments and post-termination stock-based compensation benefits. Certain employment agreements also contain clauses that require the potential payment of specified amounts to such employees upon the occurrence of a defined change in control event. Availability of Project Materials, Equipment and Labor Quanta’s customers depend on the availability of certain materials for construction, upgrade and repair and maintenance of their infrastructure and are typically responsible for supplying most or all of the materials required for the services Quanta performs on their projects, including, among other things, steel, copper, aluminum and components for renewable energy projects (e.g., solar panels, wind turbine blades). Additionally, Quanta is required to procure all or part of the materials needed for certain projects. Although there have been recent delays related to disruption in the supply chain for certain project materials, including delays with respect to solar panels during the year ended December 31, 2022, Quanta and its customers have generally been able to procure necessary materials. Quanta also depends on the availability of certain equipment, including specialty vehicles, to perform services. Based on the significant worldwide shortage of semiconductors, vehicle manufacturers experienced production delays with respect to new vehicles for Quanta’s fleet (both on-road and specialty vehicles) and vehicle parts (e.g., tires), and certain of its vehicle delivery orders scheduled for delivery in 2022 were delayed and cancelled. Quanta believes it has taken steps to secure delivery of a sufficient amount of vehicles and does not anticipate any significant disruptions with respect to its fleet in the near-term. Quanta’s success depends on its ability to attract, develop and retain highly qualified employees, including craft skilled labor, engineers, architects, designers, management and professional and administrative employees, and the industries in which Quanta operates have experienced shortages of qualified skilled labor personnel in recent years, which is expected to continue and potentially worsen in the future. In order to help meet near-term and longer term labor needs, Quanta supports and utilizes its own training and educational programs and has developed additional company-wide and project-specific employee training and educational programs and strategic relationships with universities, the military and unions to recruit qualified personnel.

X
- References No definition available. + Details
Name: | us-gaap_CommitmentsAndContingenciesDisclosureAbstract
Namespace Prefix: | us-gaap_
Data Type: | xbrli:stringItemType
Balance Type: | na
Period Type: | duration

X
- Definition The entire disclosure for commitments and contingencies. + References Reference 1: http://fasb.org/us-gaap/role/ref/legacyRef -Publisher FASB -Name Accounting Standards Codification -Topic 440 -URI https://asc.fasb.org/topic&trid=2144648 Reference 2: http://www.xbrl.org/2003/role/disclosureRef -Publisher FASB -Name Accounting Standards Codification -Topic 954 -SubTopic 440 -Section 50 -Paragraph 1 -Subparagraph (a) -URI https://asc.fasb.org/extlink&oid=6491277&loc=d3e6429-115629 Reference 3: http://www.xbrl.org/2009/role/commonPracticeRef -Publisher FASB -Name Accounting Standards Codification -Topic 450 -URI https://asc.fasb.org/topic&trid=2127136 Reference 4: http://www.xbrl.org/2003/role/disclosureRef -Publisher FASB -Name Accounting Standards Codification -Topic 440 -SubTopic 10 -Section 50 -Paragraph 4 -Subparagraph (c) -URI https://asc.fasb.org/extlink&oid=123406679&loc=d3e25336-109308 Reference 5: http://www.xbrl.org/2003/role/disclosureRef -Publisher FASB -Name Accounting Standards Codification -Topic 440 -SubTopic 10 -Section 50 -Paragraph 4 -Subparagraph (a) -URI https://asc.fasb.org/extlink&oid=123406679&loc=d3e25336-109308 + Details
Name: | us-gaap_CommitmentsAndContingenciesDisclosureTextBlock
Namespace Prefix: | us-gaap_
Data Type: | dtr-types:textBlockItemType
Balance Type: | na
Period Type: | duration