XML 36 R22.htm IDEA: XBRL DOCUMENT
v3.22.2.2

CONTINGENT LIABILITIES AND OTHER MATTERS | 9 Months Ended
--- | ---
Oct. 01, 2022
Commitments and Contingencies Disclosure [Abstract] |
CONTINGENT LIABILITIES AND OTHER MATTERS | CONTINGENT LIABILITIES AND OTHER MATTERS General Numerous claims, complaints and proceedings arising in the ordinary course of business have been asserted or are pending against us or certain of our subsidiaries (collectively, “claims”). These claims relate to litigation matters (e.g., class actions, derivative lawsuits and contracts, intellectual property and competitive claims), environmental matters, product liability matters (predominately associated with alleged exposure to asbestos-containing materials), and other risk management matters (e.g., general liability, automobile, and workers’ compensation claims). Additionally, we may become subject to other claims of which we are currently unaware, which may be significant, or the claims of which we are aware may result in our incurring significantly greater loss than we anticipate. While we (and our subsidiaries) maintain property, cargo, auto, product, general liability, environmental, and directors’ and officers’ liability insurance and have acquired rights under similar policies in connection with acquisitions that we believe cover a significant portion of these claims, this insurance may be insufficient or unavailable (e.g., in the case of insurer insolvency) to protect us against potential loss exposures. Also, while we believe we are entitled to indemnification from third parties for some of these claims, these rights may be insufficient or unavailable to protect us against potential loss exposures. Our recorded liab ilities related to these matters totaled $614.0 and $658.8 at October 1, 2022 and December 31, 2021, respectively. Of these amounts, $538.9 and $584.3 are included in “Other long-term liabilities” within our condensed consolidated balance sheets at October 1, 2022 and December 31, 2021, respectively, with the remainder included in “Accrued expenses.” The liabilities we record for these matters are based on a number of assumptions, including historical claims and payment experience. While we base our assumptions on facts currently known to us, they entail inherently subjective judgments and uncertainties. As a result, our current assumptions for estimating these liabilities may not prove accurate, and we may be required to adjust these liabilities in the future, which could result in charges to earnings. These variances relative to current expectations could have a material impact on our financial position and results of operations. Our asbestos-related claims are with respect to products that we no longer manufacture or sell and are typical in certain of the industries in which we operate or pertain to legacy businesses we no longer operate. It is not unusual in these cases for fifty or more corporate entities to be named as defendants. We vigorously defend these claims, many of which are dismissed without payment, and the significant majority of costs related to these claims have historically been paid pursuant to our insurance arrangements. Our recorded assets and liabilities related to asbestos-related claims were as follows at October 1, 2022 and December 31, 2021:
| October 1, 2022 |  | December 31, 2021
Insurance recovery assets (1) | $ | 479.8 |  |  | $ | 526.2 |
Liabilities for claims (2) | 574.6 |  | 616.5 |
__________________________ (1)Of these a mounts, $424.2 and $473.6 are included in “Other assets” at October 1, 2022 and December 31, 2021, respectively, while the remainder is included in “Other current assets.” (2)Of the se amounts, $520.4 and $561.4 are included in “Other long-term liabilities” at October 1, 2022 and December 31, 2021, respectively, while the remainder is included in “Accrued expenses.” The liabilities we record for asbestos-related claims are based on a number of assumptions. In estimating our liabilities for asbestos-related claims, we consider, among other things, the following: • The number of pending claims by disease type and jurisdiction. • Historical information by disease type and jurisdiction with regard to: ◦ Average number of claims settled with payment (versus dismissed without payment); and ◦ Average claim settlement amounts. • The period over which we can reasonably project asbestos-related claims (currently projecting through 2057). The following table presents information regarding activity for the asbestos-related claims for the nine months ended October 1, 2022 and October 2, 2021:
| Nine months ended
| October 1, 2022 |  | October 2, 2021
Pending claims, beginning of period | 10,065 |  | 9,782
Claims filed | 2,249 |  | 2,044
Claims resolved | (1,733) |  | (1,797)
Pending claims, end of period | 10,581 |  | 10,029
The assets we record for asbestos-related claims represent amounts that we believe we are or will be entitled to recover under agreements we have with insurance companies. The amount of these assets are based on a number of assumptions, including the continued solvency of the insurers and our legal interpretation of our rights for recovery under the agreements we have with the insurers. Our current assumptions for estimating these assets may not prove accurate, and we may be required to adjust these assets in the future. These variances relative to current expectations could have a material impact on our financial position and results of operations. During the nine months ended October 1, 2022 and October 2, 2021, our (receipts) payments for asbestos-related claims, net of respective insurance recoveries of $27.7 and $39.8, were $20.2 and $(2.2), respectively. The nine months ended October 1, 2021 includes insurance proceeds of $15.0, associated with the settlement of an asbestos insurance coverage matter. A significant increase in claims, costs and/or issues with existing insurance coverage (e.g., dispute with or insolvency of insurer(s)) could have a material adverse impact on our share of future payments related to these matters, and, as a result, have a material impact on our financial position, results of operations and cash flows. During the three and nine months ended October 1, 2022, we recorded charges for asbestos-related matters of $21.7 and $24.0, respectively, with $16.5 and $18.8, respectively, recorded to continuing operations and the remainder to discontinued operations. Of such charges, $21.7 (continuing operations - $16.5 and discontinued operations - $5.2) resulted from a ruling by a North Carolina trial court, during the third quarter of 2022, that certain excess insurance carriers associated with our asbestos product liability matters are not required to cover the costs of defending suits that are dismissed without an indemnity payment. During the nine months ended October 2, 2021, we recorded a charge of $2.7 related to revisions of recorded assets for asbestos-related claims. Large Power Projects in South Africa Overview - Since 2008, DBT had been executing on two large power projects in South Africa (Kusile and Medupi), on which it has now substantially completed its scope of work. Over such time, the business environment surrounding these projects was difficult, as DBT, along with many other contractors on the projects, experienced delays, cost over-runs, and various other challenges associated with a complex set of contractual relationships among the end customer, prime contractors, various subcontractors (including DBT and its subcontractors), and various suppliers. DBT's remaining responsibilities relate largely to resolution of various claims, primarily between itself and one of its prime contractors, Mitsubishi Heavy Industries Power—ZAF (f.k.a. Mitsubishi-Hitachi Power Systems Africa (PTY) LTD), or “MHI.” The challenges related to the projects have resulted in (i) significant adjustments to our revenue and cost estimates for the projects, (ii) DBT’s submission of numerous change orders to the prime contractors, (iii) various claims and disputes between DBT and other parties involved with the projects (e.g., prime contractors, subcontractors, suppliers, etc.), and (iv) the possibility that DBT may become subject to additional claims, which could be significant. It is possible that some outstanding claims may not be resolved until after the prime contractors complete their scopes of work. Our future financial position, operating results, and cash flows could be materially impacted by the resolution of current and any future claims. Claims by DBT - DBT has asserted claims against MHI of approximately South African Rand 1,000.0 (or $56.0). As DBT prepares these claims for dispute resolution processes, the amounts, along with the characterization, of the claims could change. Of these claims, South African Rand 732.6 (or $41.0), which is inclusive of the amounts awarded in the adjudications referred to below, are currently proceeding through contractual di spute resolution processes and DBT is likely to initiate additional dispute resolution processes. DBT is also pursuing several claims to force MHI to abide by its contractual obligations and provide DBT with certain benefits that MHI may have received from its customer on the projects. In addition to existing asserted claims, DBT believes it has additional claims and rights to recovery based on its performance under the contracts with, and actions taken by, MHI. DBT is continuing to evaluate the claims and the amounts owed to it under the contracts based on MHI's failure to comply with its contractual obligations. The amounts DBT may recover for current and potential future claims against MHI are not currently known given (i) the extent of current and potential future claims by MHI against DBT (see below for further discussion) and (ii) the unpredictable nature of any dispute resolution processes that may occur in connection with these current and potential future claims. No revenue has been recorded in the accompanying condensed consolidated financial statements with respect to current or potential future claims against MHI. On July 23, 2020, a dispute adjudication panel issued a ruling in favor of DBT on certain matters related to the Kusile and Medupi projects. The panel (i) ruled that DBT had achieved takeover on 9 of the units; (ii) ordered MHI to return $2.3 of bonds (which have been subsequently returned by MHI); (iii) ruled that DBT is entitled to the return of an additional $4.3 of bonds upon the completion of certain administrative milestones (which have been completed); (iv) ordered MHI to pay South African Rand 18.4 (or $1.1 at the time of the ruling) in incentive payments for work performed by DBT (which MHI has subsequently paid); and (v) ruled that MHI waived its rights to assert delay damages against DBT on one of the units of the Kusile project. The ruling is subject to MHI’s rights to seek further arbitration in the matter, as provided in the contracts. As such, the incentive payments noted above have not been recorded in our condensed consolidated statements of operations. On February 22, 2021, a dispute adjudication panel issued a ruling in favor of DBT related to costs incurred in connection with delays on two units of the Kusile project. In connection with the ruling, MHI paid DBT South African Rand 126.6 (or $8.6 at the time of payment). This ruling is subject to MHI’s rights to seek further arbitration in the matter and, thus, the amount awarded has not been reflected in our condensed consolidated statements of operations. On July 5, 2021, DBT received notice from MHI of its intent to seek final and binding arbitration in this matter. The hearing on this matter is expected to occur in December 2022. On April 28, 2021, a dispute adjudication panel issued a ruling in favor of DBT related to costs incurred in connection with delays on two units of the Medupi project. In connection with the ruling, MHI paid DBT South African Rand 82.0 (or $6.0 at the time of payment). This ruling is subject to MHI’s rights to seek further arbitration in the matter and, thus, the amount awarded has not been reflected in our condensed consolidated statements of operations. Claims by MHI - On February 26, 2019, DBT received notification of an interim claim consisting of both direct and consequential damages from MHI alleging, among other things, that DBT (i) provided defective product and (ii) failed to meet certain project milestones. In September 2020, MHI made a demand on certain bonds issued in its favor by DBT, based solely on these alleged defects, but without further substantiation or other justification (see further discussion below). On December 30, 2020, MHI notified DBT of its intent to take these claims to binding arbitration even though the vast majority of these claims had not been brought appropriately before a dispute adjudication board as required under the relevant subcontracts. On June 4, 2021, in connection with the arbitration, DBT received a revised version of the claim. Similar to the interim claim, we believe the vast majority of the damages summarized in the revised claim are unsubstantiated and, thus, any loss for the majority of these claims is considered remote. The remainder of the damages in the revised claim largely appear to be direct in nature (approximately South African Rand 790.0 or $44.2). On September 21, 2022, an arbitration tribunal ruled that only South African Rand 349.6 (or $19.6) of MHI's revised claim had been brought appropriately before a dispute adjudication board as required under the relevant subcontracts, with MHI's other claims dismissed from the arbitration proceedings. DBT has numerous defenses and, thus, we do not believe that DBT has a probable loss associated with any of these claims. As such, no loss has been recorded in the condensed consolidated financial statements with respect to these claims. DBT intends to vigorously defend itself against these claims. Although it is reasonably possible that some loss may be incurred in connection with these claims, we currently are unable to estimate the potential loss or range of potential loss associated with these claims due to the (i) lack of support provided by MHI for these claims; (ii) complexity of contractual relationships between the end customer, MHI, and DBT; (iii) legal interpretation of the contract provisions and application of South African law to the contracts; and (iv) unpredictable nature of any dispute resolution processes that may occur in connection with these claims. In April and July 2019, DBT received notifications of intent to claim liquidated damages totaling South African Rand 407.2 (or $22.8) from MHI alleging that DBT failed to meet certain project milestones related to the construction of the filters for both the Kusile and Medupi projects. DBT has numerous defenses against these claims and, thus, we do not believe that DBT has a probable loss associated with these claims. As such, no loss has been recorded in the condensed consolidated financial statements with respect to these claims. Although it is reasonably possible that some loss may be incurred in connection with these claims, we currently are unable to estimate the potenti al loss or range of potential loss. MHI has made other claims against DBT totaling South African Rand 176.2 (or $9.9) and has also alleged that it has incurred additional remedial costs related to portions of DBT's scope of work. DBT has numerous defenses against these claims, as well as claims, if any, that may result from the above unsubstantiated allegations, and, thus, we do not believe that DBT has a probable loss associated with these claims and allegations. As such, no loss has been recorded in the condensed consolidated financial statements with respect to these claims and allegations. Bonds Issued in Favor of MHI - DBT is obligated with respect to bonds issued by banks in favor of MHI. In September of 2020, MHI made a demand, and received payment of South African Rand 239.6 (or $14.3 at the time of payment), on certain of these bonds. In May 2021, MHI made an additional demand, and received payment of South African Rand 178.7 (or $12.5 at the time of payment), on certain of the remaining bonds at such time. In both cases, we funded the payment as required under the terms of the bonds and our senior credit agreement. In its demands, MHI purported that DBT failed to carry out its obligations to rectify certain alleged product defects and that DBT failed to meet certain project milestones. DBT denies liability for such allegations and, thus, fully intends to seek, and believes it is legally entitled to, reimbursement of the South African Rand 418.3 (or $23.4) that has been paid. On October 11, 2022, a dispute adjudication panel ruled MHI drew on amounts in excess of the bond values stipulated in the contracts and was required to refund DBT South African Rand 90.8 (or $5.1) of the previously demanded amounts, plus interest of South African Rand 12.5 (or $0.7). MHI paid these amounts on October 14, 2022. We have reflected the remaining South African Rand 327.5 (or $18.3) within “Assets of DBT and Heat Transfer” on the condensed consolidated balance sheets as of October 1, 2022 and December 31, 2021. The remaining bond of South Africa Rand 29.2 (or $1.6) issued to MHI as a performance guarantee could be exercised by MHI for an alleged breach of DBT's obligation. In the event that MHI were to receive payment on a portion, or all, of the remaining bond, we would be required to reimburse the issuing bank. In addition to the remaining bond, SPX Technologies, Inc. has guaranteed DBT’s performance on these projects to the prime contractors, including MHI. Claim against Surety - On February 5, 2021, DBT received payment of $6.7 on bonds issued in support of performance by one of DBT's sub-contractors. The sub-contractor maintains a right to seek recovery of such amount and, thus, the amount received by DBT has not been reflected in our condensed consolidated statements of operations. Litigation Matters We are subject to other legal matters that arise in the normal course of business. We believe these matters are either without merit or of a kind that should not have a material effect, individually or in the aggregate, on our financial position, results of operations or cash flows; however, we cannot assure you that these proceedings or claims will not have a material effect on our financial position, results of operations or cash flows. Environmental Matters Our operations and properties are subject to federal, state, local and foreign regulatory requirements relating to environmental protection. It is our policy to comply fully with all applicable requirements. As part of our effort to comply, we have a comprehensive environmental compliance program that includes environmental audits conducted by internal and external independent professionals, as well as regular communications with our operating units regarding environmental compliance requirements and anticipated regulations. Based on current information, we believe that our operations are in substantial compliance with applicable environmental laws and regulations, and we are not aware of any violations that could have a material effect, individually or in the aggregate, on our business, financial condition, and results of operations or cash flows. We had liabilities for site investigation and/or remediation at 18 sites that we own or control, or formerly owned and controlled, as of October 1, 2022 and December 31, 2021. In addition, while we believe that we maintain adequate accruals to cover the costs of site investigation and/or remediation, we cannot provide assurance that new matters, developments, laws and regulations, or stricter interpretations of existing laws and regulations will not materially affect our business or operations in the future. Our environmental accruals cover anticipated costs, including investigation, remediation, and maintenance of clean-up sites. Our estimates are based primarily on investigations and remediation plans established by independent consultants, regulatory agencies and potentially responsible third parties. Accordingly, our estimates may change based on future developments, including new or changes in existing environmental laws or policies, differences in costs required to complete anticipated actions from estimates provided, future findings of investigation or remediation actions, or alteration to the expected remediation plans. It is our policy to revise an estimate once the revision becomes probable and the amount of change can be reasonably estimated. We generally do not discount our environmental accruals and do not reduce them by anticipated insurance recoveries. We take into account third-party indemnification from financially viable parties in determining our accruals where there is no dispute regarding the right to indemnification. In the case of contamination at offsite, third-party disposal sites, as of October 1, 2022 and December 31, 2021, we have been notified that we are potentially responsible and have received other notices of potential liability pursuant to various environmental laws at 9 sites, at which the liability has not been settled and all of which have been active in the past few years. These laws may impose liability on certain persons that are considered jointly and severally liable for the costs of investigation and remediation of hazardous substances present at these sites, regardless of fault or legality of the original disposal. These persons include the present or former owners or operators of the site and companies that generated, disposed of or arranged for the disposal of hazardous substances at the site. We are considered a “de minimis” potentially responsible party at most of the sites, and we estimate that our aggregate liability, if any, related to these sites is not material to our condensed consolidated financial statements. We conduct extensive environmental due diligence with respect to potential acquisitions, including environmental site assessments and such further testing as we may deem warranted. If an environmental matter is identified, we estimate the cost and either establish a liability, purchase insurance or obtain an indemnity from a financially sound seller; however, in connection with our acquisitions or dispositions, we may assume or retain significant environmental liabilities, some of which we may be unaware. The potential costs related to these environmental matters and the possible impact on future operations are uncertain due in part to the complexity of government laws and regulations and their interpretations, the varying costs and effectiveness of various clean-up technologies, the uncertain level of insurance or other types of recovery, and the questionable level of our responsibility. We record a liability when it is both probable and the amount can be reasonably estimated. In our opinion, after considering accruals established for such purposes, the cost of remedial actions for compliance with the present laws and regulations governing the protection of the environment are not expected to have a material impact, individually or in the aggregate, on our financial position, results of operations or cash flows. Self-insured Risk Management Matters We are self-insured for certain of our workers’ compensation, automobile, product and general liability, disability and health costs, and we believe that we maintain adequate accruals to cover our retained liability. Our accruals for risk management matters are determined by us, are based on claims filed and estimates of claims incurred but not yet reported, and generally are not discounted. We consider a number of factors, including third-party actuarial valuations, when making these determinations. We maintain third-party stop-loss insurance policies to cover certain liability costs in excess of predetermined retained amounts. The insurance may be insufficient or unavailable (e.g., because of insurer insolvency) to protect us against loss exposure.

X
- References No definition available. + Details
Name: | us-gaap_CommitmentsAndContingenciesDisclosureAbstract
Namespace Prefix: | us-gaap_
Data Type: | xbrli:stringItemType
Balance Type: | na
Period Type: | duration

X
- Definition The entire disclosure for commitments and contingencies. + References Reference 1: http://fasb.org/us-gaap/role/ref/legacyRef -Publisher FASB -Name Accounting Standards Codification -Topic 440 -URI https://asc.fasb.org/topic&trid=2144648 Reference 2: http://www.xbrl.org/2003/role/disclosureRef -Publisher FASB -Name Accounting Standards Codification -Topic 954 -SubTopic 440 -Section 50 -Paragraph 1 -Subparagraph (a) -URI https://asc.fasb.org/extlink&oid=6491277&loc=d3e6429-115629 Reference 3: http://www.xbrl.org/2009/role/commonPracticeRef -Publisher FASB -Name Accounting Standards Codification -Topic 450 -URI https://asc.fasb.org/topic&trid=2127136 Reference 4: http://www.xbrl.org/2003/role/disclosureRef -Publisher FASB -Name Accounting Standards Codification -Topic 440 -SubTopic 10 -Section 50 -Paragraph 4 -Subparagraph (c) -URI https://asc.fasb.org/extlink&oid=123406679&loc=d3e25336-109308 Reference 5: http://www.xbrl.org/2003/role/disclosureRef -Publisher FASB -Name Accounting Standards Codification -Topic 440 -SubTopic 10 -Section 50 -Paragraph 4 -Subparagraph (a) -URI https://asc.fasb.org/extlink&oid=123406679&loc=d3e25336-109308 + Details
Name: | us-gaap_CommitmentsAndContingenciesDisclosureTextBlock
Namespace Prefix: | us-gaap_
Data Type: | dtr-types:textBlockItemType
Balance Type: | na
Period Type: | duration