<SEC-DOCUMENT>0001193125-17-327150.txt : 20171031
<SEC-HEADER>0001193125-17-327150.hdr.sgml : 20171031
<ACCEPTANCE-DATETIME>20171031160557
ACCESSION NUMBER:		0001193125-17-327150
CONFORMED SUBMISSION TYPE:	8-K
PUBLIC DOCUMENT COUNT:		3
CONFORMED PERIOD OF REPORT:	20171026
ITEM INFORMATION:		Creation of a Direct Financial Obligation or an Obligation under an Off-Balance Sheet Arrangement of a Registrant
ITEM INFORMATION:		Financial Statements and Exhibits
FILED AS OF DATE:		20171031
DATE AS OF CHANGE:		20171031

FILER:

	COMPANY DATA:	
		COMPANY CONFORMED NAME:			AMERICAN OUTDOOR BRANDS CORP
		CENTRAL INDEX KEY:			0001092796
		STANDARD INDUSTRIAL CLASSIFICATION:	ORDNANCE & ACCESSORIES, (NO VEHICLES/GUIDED MISSILES) [3480]
		IRS NUMBER:				870543688
		STATE OF INCORPORATION:			NV
		FISCAL YEAR END:			0430

	FILING VALUES:
		FORM TYPE:		8-K
		SEC ACT:		1934 Act
		SEC FILE NUMBER:	001-31552
		FILM NUMBER:		171165761

	BUSINESS ADDRESS:	
		STREET 1:		2100 ROOSEVELT AVENUE
		CITY:			SPRINGFIELD
		STATE:			MA
		ZIP:			01104
		BUSINESS PHONE:		844-363-5386

	MAIL ADDRESS:	
		STREET 1:		2100 ROOSEVELT AVENUE
		CITY:			SPRINGFIELD
		STATE:			MA
		ZIP:			01104

	FORMER COMPANY:	
		FORMER CONFORMED NAME:	AMERICAN OUTDOOR BRANDS CORPORATON
		DATE OF NAME CHANGE:	20170103

	FORMER COMPANY:	
		FORMER CONFORMED NAME:	SMITH & WESSON HOLDING CORP
		DATE OF NAME CHANGE:	20020315

	FORMER COMPANY:	
		FORMER CONFORMED NAME:	SAF T HAMMER CORP/NV
		DATE OF NAME CHANGE:	20000404
</SEC-HEADER>
<DOCUMENT>
<TYPE>8-K
<SEQUENCE>1
<FILENAME>d479247d8k.htm
<DESCRIPTION>8-K
<TEXT>
<HTML><HEAD>
<TITLE>8-K</TITLE>
</HEAD>
 <BODY BGCOLOR="WHITE">

 <P STYLE="line-height:1.0pt;margin-top:0pt;margin-bottom:0pt;border-bottom:1px solid #000000">&nbsp;</P>
<P STYLE="line-height:3.0pt;margin-top:0pt;margin-bottom:2pt;border-bottom:1px solid #000000">&nbsp;</P> <P STYLE="margin-top:4pt; margin-bottom:0pt; font-size:18pt; font-family:Times New Roman" ALIGN="center"><B>UNITED STATES </B></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:18pt; font-family:Times New Roman" ALIGN="center"><B>SECURITIES AND EXCHANGE COMMISSION </B></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:12pt; font-family:Times New Roman" ALIGN="center"><B>Washington, D.C. 20549 </B></P> <P STYLE="font-size:12pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P><center>
<P STYLE="line-height:6.0pt;margin-top:0pt;margin-bottom:2pt;border-bottom:1.00pt solid #000000;width:21%">&nbsp;</P></center> <P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:18pt; font-family:Times New Roman" ALIGN="center"><B>FORM <FONT
STYLE="white-space:nowrap">8-K</FONT> </B></P> <P STYLE="font-size:12pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P><center>
<P STYLE="line-height:6.0pt;margin-top:0pt;margin-bottom:2pt;border-bottom:1.00pt solid #000000;width:21%">&nbsp;</P></center> <P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:12pt; font-family:Times New Roman" ALIGN="center"><B>CURRENT
REPORT </B></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:12pt; font-family:Times New Roman" ALIGN="center"><B>Pursuant to Section&nbsp;13 or 15(d) </B></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:12pt; font-family:Times New Roman" ALIGN="center"><B>of the Securities Exchange Act of 1934 </B></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:12pt; font-family:Times New Roman" ALIGN="center"><B>Date of Report (Date of earliest event reported): October&nbsp;26, 2017 </B></P>
<P STYLE="font-size:12pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P><center> <P STYLE="line-height:6.0pt;margin-top:0pt;margin-bottom:2pt;border-bottom:1.00pt solid #000000;width:21%">&nbsp;</P></center>
<P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:24pt; font-family:Times New Roman" ALIGN="center"><B>American Outdoor Brands Corporation </B></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><B>(Exact Name of Registrant as Specified in Charter) </B></P> <P STYLE="font-size:12pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P><center>
<P STYLE="line-height:6.0pt;margin-top:0pt;margin-bottom:2pt;border-bottom:1.00pt solid #000000;width:21%">&nbsp;</P></center> <P STYLE="font-size:12pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P>
<TABLE CELLSPACING="0" CELLPADDING="0" WIDTH="100%" BORDER="0" STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:8pt" ALIGN="center">


<TR>
<TD WIDTH="34%"></TD>
<TD VALIGN="bottom"></TD>
<TD WIDTH="32%"></TD>
<TD VALIGN="bottom" WIDTH="1%"></TD>
<TD WIDTH="32%"></TD></TR>


<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top" ALIGN="center"><B>Nevada</B></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="top" ALIGN="center"><B><FONT STYLE="white-space:nowrap">001-31552</FONT></B></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="top" ALIGN="center"><B><FONT STYLE="white-space:nowrap">87-0543688</FONT></B></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:8pt">
<TD VALIGN="top" ALIGN="center"> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:8pt; font-family:Times New Roman" ALIGN="center"><B>(State or other jurisdiction</B></P>
<P STYLE="margin-top:0pt; margin-bottom:1pt; font-size:8pt; font-family:Times New Roman" ALIGN="center"><B>of incorporation)</B></P></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="top" ALIGN="center"> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:8pt; font-family:Times New Roman" ALIGN="center"><B>(Commission</B></P>
<P STYLE="margin-top:0pt; margin-bottom:1pt; font-size:8pt; font-family:Times New Roman" ALIGN="center"><B>File Number)</B></P></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="top" ALIGN="center"> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:8pt; font-family:Times New Roman" ALIGN="center"><B>(IRS Employer</B></P>
<P STYLE="margin-top:0pt; margin-bottom:1pt; font-size:8pt; font-family:Times New Roman" ALIGN="center"><B>Identification No.)</B></P></TD></TR>
</TABLE> <P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><B>2100 Roosevelt Avenue </B></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><B>Springfield, Massachusetts </B></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:8pt; font-family:Times New Roman" ALIGN="center"><B>(Address of principal executive offices) (Zip Code) </B></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><B>(800) <FONT STYLE="white-space:nowrap">331-0852</FONT> </B></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:8pt; font-family:Times New Roman" ALIGN="center"><B>(Registrant&#146;s telephone number, including area code) </B></P>
<P STYLE="font-size:12pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P><center> <P STYLE="line-height:6.0pt;margin-top:0pt;margin-bottom:2pt;border-bottom:1.00pt solid #000000;width:21%">&nbsp;</P></center>
<P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman">Check the appropriate box below if the Form <FONT STYLE="white-space:nowrap">8-K</FONT> filing is intended to simultaneously satisfy the filing obligation of
the registrant under any of the following provisions (see General Instruction A.2. below): </P> <P STYLE="font-size:6pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P>
<TABLE STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:10pt" BORDER="0" CELLPADDING="0" CELLSPACING="0" WIDTH="100%">
<TR style = "page-break-inside:avoid">
<TD WIDTH="4%" VALIGN="top" ALIGN="left">&#9744;</TD>
<TD ALIGN="left" VALIGN="top">Written communications pursuant to Rule 425 under the Securities Act (17 CFR 230.425) </TD></TR></TABLE> <P STYLE="font-size:6pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P>
<TABLE STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:10pt" BORDER="0" CELLPADDING="0" CELLSPACING="0" WIDTH="100%">
<TR style = "page-break-inside:avoid">
<TD WIDTH="4%" VALIGN="top" ALIGN="left">&#9744;</TD>
<TD ALIGN="left" VALIGN="top">Soliciting material pursuant to Rule <FONT STYLE="white-space:nowrap">14a-12</FONT> under the Exchange Act (17 CFR <FONT STYLE="white-space:nowrap">240.14a-12)</FONT> </TD></TR></TABLE>
<P STYLE="font-size:6pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P>
<TABLE STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:10pt" BORDER="0" CELLPADDING="0" CELLSPACING="0" WIDTH="100%">
<TR style = "page-break-inside:avoid">
<TD WIDTH="4%" VALIGN="top" ALIGN="left">&#9744;</TD>
<TD ALIGN="left" VALIGN="top"><FONT STYLE="white-space:nowrap">Pre-commencement</FONT> communications pursuant to Rule <FONT STYLE="white-space:nowrap">14d-2(b)</FONT> under the Exchange Act (17 CFR
<FONT STYLE="white-space:nowrap">240.14d-2(b))</FONT> </TD></TR></TABLE> <P STYLE="font-size:6pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P>
<TABLE STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:10pt" BORDER="0" CELLPADDING="0" CELLSPACING="0" WIDTH="100%">
<TR style = "page-break-inside:avoid">
<TD WIDTH="4%" VALIGN="top" ALIGN="left">&#9744;</TD>
<TD ALIGN="left" VALIGN="top"><FONT STYLE="white-space:nowrap">Pre-commencement</FONT> communications pursuant to Rule <FONT STYLE="white-space:nowrap">13e-4(c)</FONT> under the Exchange Act (17 CFR
<FONT STYLE="white-space:nowrap">240.13e-4(c))</FONT> </TD></TR></TABLE> <P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman">Indicate by check mark whether the registrant is an emerging growth company as
defined in Rule 405 of the Securities Act of 1933 (17&nbsp;&#167;CRF 230.405) or Rule <FONT STYLE="white-space:nowrap">12b-2</FONT> of the Securities Exchange Act of 1934 (17 CFR <FONT STYLE="white-space:nowrap">&#167;240.12b-2).</FONT> </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman">Emerging growth company&nbsp;&nbsp;&#9744; </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman">If an emerging
growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section&nbsp;13(a) of the Exchange
Act.&nbsp;&nbsp;&#9744; </P> <P STYLE="font-size:10pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P> <P STYLE="line-height:1.0pt;margin-top:0pt;margin-bottom:0pt;border-bottom:1px solid #000000">&nbsp;</P>
<P STYLE="line-height:3.0pt;margin-top:0pt;margin-bottom:2pt;border-bottom:1px solid #000000">&nbsp;</P>

<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman"><B>Item&nbsp;2.03 Creation of a Direct Financial Obligation or an Obligation under an <FONT
STYLE="white-space:nowrap">Off-Balance</FONT> Sheet Arrangement of a Registrant. </B></P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman">On October&nbsp;26, 2017, our wholly owned
subsidiary, Smith&nbsp;&amp; Wesson Corp., or Smith&nbsp;&amp; Wesson, as tenant entered into a lease agreement, or the Lease, with Ryan Boone County, LLC, an affiliate of Ryan Companies US, Inc. as landlord for the design, construction, and lease
of an approximately 632,000 square foot national distribution center in the Columbia area of Boone County, Missouri. Smith&nbsp;&amp; Wesson has the option to cause the distribution center to be expanded by up to 491,000 square feet. The initial
term of the Lease is 20 years commencing on the rent commencement date, which is expected to begin in the second half of fiscal 2019. The Lease contains six, five-year options to extend the lease term. The base rent is calculated as a percentage
multiplied by the project costs. The annual lease expense, including base rent, is estimated at between $3.3&nbsp;million and $3.5&nbsp;million. Capital expenditures for furniture, fixtures, equipment, and IT infrastructure are estimated at between
$22&nbsp;million and $24&nbsp;million and are expected to be incurred in fiscal years 2018 and 2019. Smith&nbsp;&amp; Wesson is expected to receive various tax and other incentives from federal, state, and local governmental authorities. Under the
Lease, Smith&nbsp;&amp; Wesson has a <FONT STYLE="white-space:nowrap">one-time</FONT> right to purchase the distribution center and, under certain circumstances, may share with the Landlord any gain on the sale of the property to a third-party. We
have guaranteed the Lease. We expect the Lease to be classified as a capital lease under generally accepted accounting principles. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman">The
above summary of the Lease and Guaranty are qualified in their entirety by reference to the complete terms and provisions of the Lease and Guaranty, which are attached hereto as Exhibits 10.114 and 10.115, respectively, and incorporated herein by
reference. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman">Certain statements contained in this Current Report on Form <FONT STYLE="white-space:nowrap">8-K</FONT> may be deemed to be
forward-looking statements under federal securities laws, and we intend that such forward-looking statements be subject to the safe-harbor created thereby. Such forward-looking statements include, among others, our expectations regarding the design
and construction of an approximately 632,000 square foot national distribution center in the Columbia area of Boone County, Missouri; the provisions of the Lease, which may cause the obligations described above to be incurred on different terms; and
estimates regarding the timing and amount of the annual lease expense and capital expenditures. We caution that these statements are qualified by important factors that could cause actual results to differ materially from those reflected by such
forward-looking statements. Such factors include the risks associated with the establishment of our new national distribution center and other factors detailed from time to time in our reports filed with the Securities and Exchange Commission, or
the SEC, including our Annual Report on Form <FONT STYLE="white-space:nowrap">10-K</FONT> for the fiscal year ended April&nbsp;30, 2017, filed with the SEC on June&nbsp;29, 2017. We do not have, and expressly disclaim, any obligation to release
publicly any updates or any changes in our expectations or any change in events, conditions, or circumstances on which any forward-looking statement is based. </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman"><B>Item&nbsp;9.01 Financial Statements and Exhibits. </B></P> <P STYLE="margin-top:6pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman"><B>(d)
Exhibits </B></P> <P STYLE="font-size:12pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P>
<TABLE CELLSPACING="0" CELLPADDING="0" WIDTH="100%" BORDER="0" STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:10pt" ALIGN="center">


<TR>
<TD></TD>
<TD VALIGN="bottom" WIDTH="3%"></TD>
<TD WIDTH="92%"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:8pt">
<TD VALIGN="bottom" NOWRAP ALIGN="center"> <P STYLE=" margin-top:0pt ; margin-bottom:0pt; border-bottom:1.00pt solid #000000; width:23.50pt; font-size:8pt; font-family:Times New Roman" ALIGN="center">Exhibit<BR>No.</P></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="bottom" NOWRAP ALIGN="center"> <P STYLE=" margin-top:0pt ; margin-bottom:0pt; border-bottom:1.00pt solid #000000; width:23.50pt; font-size:8pt; font-family:Times New Roman" ALIGN="center">Exhibit</P></TD></TR>


<TR STYLE="font-size:1pt">
<TD HEIGHT="8"></TD>
<TD HEIGHT="8" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top" NOWRAP>10.114</TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top">Lease Agreement, dated October&nbsp;26, 2017, by and between Ryan Boone County, LLC and Smith&nbsp;&amp; Wesson Corp.</TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="8"></TD>
<TD HEIGHT="8" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top" NOWRAP>10.115</TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top">Guaranty, dated October&nbsp;26, 2017, entered into by American Outdoor Brands Corporation</TD></TR>
</TABLE>

<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><B>EXHIBIT INDEX </B></P> <P STYLE="font-size:12pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P>
<TABLE CELLSPACING="0" CELLPADDING="0" WIDTH="100%" BORDER="0" STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:10pt" ALIGN="center">


<TR>
<TD></TD>
<TD VALIGN="bottom" WIDTH="3%"></TD>
<TD WIDTH="92%"></TD></TR>


<TR STYLE="font-size:1pt">
<TD HEIGHT="8"></TD>
<TD HEIGHT="8" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top" NOWRAP>10.114</TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"><A HREF="d479247dex10114.htm">Lease Agreement, dated October&nbsp;26, 2017, by and between Ryan Boone County, LLC and Smith&nbsp;&amp; Wesson Corp. </A></TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="8"></TD>
<TD HEIGHT="8" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top" NOWRAP>10.115</TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"><A HREF="d479247dex10115.htm">Guaranty, dated October&nbsp;26, 2017, entered into by American Outdoor Brands Corporation </A></TD></TR>
</TABLE>

<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><B>SIGNATURES </B></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman">Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by
the undersigned hereunto duly authorized. </P> <P STYLE="font-size:12pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P>
<TABLE CELLSPACING="0" CELLPADDING="0" WIDTH="100%" BORDER="0" STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:10pt">


<TR>
<TD WIDTH="46%"></TD>
<TD VALIGN="bottom" WIDTH="1%"></TD>
<TD WIDTH="4%"></TD>
<TD VALIGN="bottom"></TD>
<TD WIDTH="2%"></TD>
<TD VALIGN="bottom" WIDTH="1%"></TD>
<TD WIDTH="45%"></TD></TR>


<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="top" COLSPAN="5">AMERICAN OUTDOOR BRANDS CORPORATION</TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="16"></TD>
<TD HEIGHT="16" COLSPAN="2"></TD>
<TD HEIGHT="16" COLSPAN="2"></TD>
<TD HEIGHT="16" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top">Date: October&nbsp;31, 2017</TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="top">By:</TD>
<TD VALIGN="bottom" STYLE=" BORDER-BOTTOM:1px solid #000000">&nbsp;</TD>
<TD VALIGN="top" STYLE="BORDER-BOTTOM:1px solid #000000"><I>/s/ Jeffrey D. Buchanan</I></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="bottom"></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="bottom">Jeffrey D. Buchanan</TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="bottom"></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="bottom">Executive Vice President, Chief Financial Officer,</TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="bottom"></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;</TD>
<TD VALIGN="bottom">Chief Administrative Officer, and Treasurer</TD></TR>
</TABLE>
</BODY></HTML>
</TEXT>
</DOCUMENT>
<DOCUMENT>
<TYPE>EX-10.114
<SEQUENCE>2
<FILENAME>d479247dex10114.htm
<DESCRIPTION>EX-10.114
<TEXT>
<HTML><HEAD>
<TITLE>EX-10.114</TITLE>
</HEAD>
 <BODY BGCOLOR="WHITE">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="right"><B>Exhibit 10.114 </B></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:11pt; font-family:Times New Roman" ALIGN="center">LEASE AGREEMENT </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">THIS LEASE AGREEMENT (the &#147;Lease&#148;) is made and entered into as of the 26th day of October, 2017 (the &#147;Effective
Date&#148;), by and between RYAN BOONE COUNTY, LLC, a Minnesota limited liability company (&#147;Landlord&#148;), and SMITH&nbsp;&amp; WESSON CORP., a Delaware corporation (&#147;Tenant&#148;). </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:11pt; font-family:Times New Roman" ALIGN="center">WITNESSETH: </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">WHEREAS, Landlord owns that certain real property located in Boone County, Missouri and more particularly described in
<U><B>Exhibit&nbsp;A</B></U> (the &#147;Land&#148;); and </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">WHEREAS, Landlord has agreed to design and construct an
approximately 632,774 square foot office and warehouse building, together with related improvements, on the Land (the &#147;Project&#148;) and lease the same to Tenant, upon the terms and conditions set forth herein; and </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">WHEREAS, Landlord has agreed to cause the plans, specifications and the development budget for the Project to be completed in
accordance with the terms of this Lease, and Landlord has agreed to obtain all permits, licenses, land use entitlements and other approvals necessary for Landlord to construct the Project and for the Project to be used and occupied for office and
warehouse purposes and activities incidental thereto. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">NOW, THEREFORE, for the covenants and agreements contained herein,
and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Landlord and Tenant agree as follows: </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE I </U></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>DEFINITIONS
AND CONSTRUCTION </U></P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">1.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Defined Terms</U>. In addition to the terms defined in the other
provisions of this Lease, the following terms shall have the meanings ascribed to them in this section: </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(i)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Affiliate&#148; means, with respect to any party (the &#147;Designated Party&#148;), (A) any
Person that, directly or indirectly, controls, is controlled by, or is under common control with the Designated Party, (B)&nbsp;any Person that, directly or indirectly, owns fifty percent (50%) or more of the voting interests or financial interests
of the Designated Party, and (C)&nbsp;any Person in which the Designated Party or a Person described in subparagraph (B), directly or indirectly, owns fifty percent (50%) or more of the voting interests or financial interests. As used in the
preceding sentence, the terms &#147;control&#148;, &#147;controlled by&#148; and &#147;under common control with&#148; mean the possession of the power to direct or cause the direction of the management and policies of an entity, whether through the
ownership of voting securities, by contract or otherwise. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(ii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Alterations&#148; means any
alterations, additions, changes or improvements to the Premises, excluding maintenance, repairs and replacements (with substantially similar items). </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(iii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Applicable Laws&#148; means all applicable governmental laws, statutes, codes, ordinances,
rulings, regulations, orders and decrees, now in force or hereafter enacted, including, without limitation, the Americans with Disabilities Act, 42 U.S.C. &#167; 12101, et seq., or any successor thereto. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(iv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Architect&#148; means Heitman Architects Incorporated. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-1- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(v)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Building&#148; means the building forming a part
of the Premises, as the same is modified, from time to time. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(vi)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Business Days&#148; means
Monday through Friday, excluding holidays on which national banking associations are authorized to be closed in Boone County, Missouri. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(vii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Change Order&#148; means a written change to the Final Plans and Specifications or
Landlord&#146;s Work, which will include any consequential changes to the Schedule of Time or the Guaranteed Maximum Project Costs that are agreed upon Landlord and Tenant, in writing, or initiated by Tenant in accordance with the terms of this
Lease, including, but not limited to, <B><U>Exhibit&nbsp;B</U></B>. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(viii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Construction
Loan&#148; means the initial loan provided by a bank or other institutional lender to Landlord to fund the costs of constructing the Landlord&#146;s Work, if any. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(ix)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Contractor&#148; means Ryan Companies US, Inc., a Minnesota corporation. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(x)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Contractor&#146;s Fee&#148; shall have the meaning ascribed to it in Section&nbsp;2(d) of
<B><U>Exhibit&nbsp;B</U></B>. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xi)&nbsp;&nbsp;&nbsp;&nbsp;&#147;County&#148; means Boone County, Missouri. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;CPI Index&#148; means the Consumer Price Index for All Urban Consumers (1982 1984 = 100),
U.S. City Average&nbsp;&#150; &#147;All Items Less Food and Energy&#148; published by the Bureau of Labor Statistics of the United States Department of Labor; provided, however, if such index is discontinued, Tenant shall choose a comparable method
for measuring the relative purchasing power of the dollar that is acceptable to Landlord, in its reasonable judgment, and the same shall be substituted for such index and shall be the &#147;CPI Index&#148; thereafter. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xiii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Delivery Date&#148; means, subject to the other terms hereof (including, but not limited
to, Section&nbsp;3.01), the date Landlord delivers exclusive possession of the Premises to Tenant with Substantial Completion having occurred. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xiv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Delivery Deadline&#148; means October&nbsp;22, 2018, subject to the provisions of
Section&nbsp;3.01 of this Lease and Section&nbsp;5 of <B><U>Exhibit&nbsp;B</U></B>. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Design Requirements&#148; shall have the meaning ascribed to it on
<B><U>Exhibit&nbsp;B</U></B>. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xvi)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Development Fee&#148; shall have the meaning ascribed to
it in Section&nbsp;2(b) of <B><U>Exhibit&nbsp;B</U></B>. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xvii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Estimated Gross Building
Area&#148; means the total building area of the Building (expressed in square feet and rounded to the nearest foot) as set forth in the Final Plans and Specifications, determined in accordance with the BOMA International and the Society of
Industrial and Office Realtors Standard Method for Measuring Floor Area in Industrial Buildings, ANSI/BOMA Z65.2&nbsp;&#150; 2012. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xviii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Event of Force Majeure&#148; means any strike, lockout, labor dispute, embargo, flood,
earthquake, storm, lightning, fire, casualty, epidemic, act of God, war, national emergency, civil disturbance or disobedience, riot, sabotage, terrorism, restraint by court order, unusually severe weather conditions not reasonably anticipatable, or
other occurrence beyond the reasonable control of the party in </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-2- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
question; provided, however, Landlord&#146;s or Tenant&#146;s lack of funds shall not constitute an Event of Force Majeure. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xix)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Extension Option&#148; shall have the meaning ascribed to it in Section&nbsp;4.02. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xx)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Extension Period&#148; shall have the meaning ascribed to it in Section&nbsp;4.02. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxi)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Final Completion&#148; means the full and proper completion of all of Landlord&#146;s Work
in accordance with the terms of this Lease, including, but not limited to, the correction of all Minor Punch List Items, and the issuance of a final and unconditional certificate of occupancy of the Premises. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Final Plans and Specifications&#148; shall have the meaning set forth on
<B><U>Exhibit&nbsp;B</U></B>; provided the Final Plans and Specifications shall be modified by any Change Order approved by Tenant, in writing, in accordance with said <B><U>Exhibit&nbsp;B</U></B>. Once the Final Plans and Specifications have been
approved by both Landlord and Tenant, the parties shall execute an amendment to this Lease attaching the same or a detailed description thereof as <B><U>Exhibit&nbsp;C</U></B> to this Lease. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxiii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;General Conditions Costs&#148; shall have the meaning ascribed to it on
<B><U>Exhibit&nbsp;B</U></B>. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxiv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Gross Building Area&#148; means the total building area
of the Building (expressed in square feet and rounded to the nearest foot), as constructed, determined in accordance with the BOMA International and the Society of Industrial and Office Realtors Standard Method for Measuring Floor Area in Industrial
Buildings, ANSI/BOMA Z65.2&nbsp;&#150; 2012. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Guaranteed Maximum Project Costs&#148;
shall have the meaning ascribed to it on <B><U>Exhibit&nbsp;B</U></B>, as the same is increased in accordance with Sections&nbsp;2.02(d) and 3.01(i) of this Lease and Sections 1(c), 2(l), and 5 of <B><U>Exhibit&nbsp;B</U></B>. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxvi)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Hazardous Substances&#148; means all hazardous or toxic substances, materials, wastes,
pollutants and contaminants that are listed, defined or regulated under Applicable Laws pertaining to the environment human health or safety, including, but not limited to, the Comprehensive Environmental Response, Compensation, and Liability Act,
42&nbsp;U.S.C.A. &#167;&#167;&nbsp;9601 to 9675, the Hazardous Materials Transportation Authorization Act of 1994, 49&nbsp;U.S.C.A. &#167;&nbsp;5101 et seq., the Resource Conservation and Recovery Act, 42&nbsp;U.S.C.A. &#167;&#167;&nbsp;6921 to
6939e, the Federal Water Pollution Control Act, 33&nbsp;U.S.C.A. &#167;&#167;&nbsp;1251 to 1387, the Clean Air Act, 42&nbsp;U.S.C.A.&nbsp;&#167;&#167; 7401 to 7671q, the Emergency Planning and Community Right To Know Act, 42&nbsp;U.S.C.A.
&#167;&#167;&nbsp;11001 to 11050, the Toxic Substances Control Act, 15 U.S.C.A. &#167;&#167;&nbsp;2601 to 2692, the Solid Waste Disposal Act, 42&nbsp;U.S.C.A. &#167;&#167;&nbsp;6901 to 6992k, the Oil Pollution Act, 33&nbsp;U.S.C.A.
&#167;&#167;&nbsp;2701 to 2761, and the environmental laws of the State of Missouri, each as amended. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxvii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Improvements&#148; means the buildings, structures and other improvements located on the
Land, including, but not limited to, Landlord&#146;s Work, as the same are modified, from time to time. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxviii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Incentive Agreements&#148; means the final documents and other agreements as executed by
the applicable parties, which shall be substantially in the form attached to the Incentive Memorandum. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxix)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Incentive Memorandum&#148; means that certain letter delivered to the County and Landlord
by Tenant, of even date herewith, enclosing substantially final forms of certain incentive </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-3- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
documents in connection with the Project, including, without limitation, documents providing for the issuance of industrial development revenue bonds for the purpose of providing funds to pay
costs permitted under Article&nbsp;VI, Section&nbsp;27(b) of the Missouri Constitution and Sections 100.010 through 100.200 of the Revised Statutes of Missouri, as amended (&#147;Ch.&nbsp;100&#148;), the making of certain payments to the County in
lieu of the property taxes that would otherwise be due with respect to the Project, and abatement of certain sale taxes. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxx)&nbsp;&nbsp;&nbsp;&nbsp;&#147;IT Room&#148; means the office area identified as the &#147;IT Server Room&#148; on
drawing&nbsp;A2.2 of <B><U><FONT STYLE="white-space:nowrap">Exhibit&nbsp;B-1</FONT></U></B>. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxxi)&nbsp;&nbsp;&nbsp;&nbsp;&#147;IT Room Ready Condition&#148; means all wall partitions installed, taped and painted, floor
and ceiling finishes complete, specialty fire protection systems installed, commissioned and operational, HVAC cooling installed, commissioned and fully operational, electrical lighting complete, electrical power complete and ready for use and all
conduit infrastructure for Tenant cabling installed for both incoming internet circuits and low voltage cabling infrastructure within the IT Room. A lockable door shall be provided at the IT Room. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxxii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;IT Room Delivery Date&#148; means the date that is sixty (60)&nbsp;days after the MHE
Access Date. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxxiii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Land&#148; shall have the meaning ascribed to it in the first (1<SUP
STYLE="font-size:85%; vertical-align:top">st</SUP>) recital of this Lease. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxxiv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Landlord&#146;s Equity Investment&#148; means the funds belonging to Landlord (as opposed
to funds from a loan, Tenant or its Affiliates, or a third party) that were actually used to pay Project Costs. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxxv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Landlord&#146;s &#147;Permitted Equity Return&#148; means an amount equal to an eight
percent (8%) annual return on Landlord&#146;s Equity Investment, which return shall (A)&nbsp;begin to accrue with respect to each portion of Landlord&#146;s Equity Investment, on the date such portion of Landlord&#146;s Equity Investment is actually
used to pay Project Costs, determined on a daily basis, and (B)&nbsp;cease to accrue on the earlier of the Delivery Date or the Delivery Deadline; provided, in no event shall Landlord&#146;s Permitted Equity Return exceed Four Hundred Fifty Six
Thousand and No/100 Dollars ($456,000.00), in the aggregate, or begin to accrue with respect to any portion of Landlord&#146;s Equity Investment prior to the Effective Date. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxxvi)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Landlord Related Parties&#148; means (A)&nbsp;Landlord, its Affiliates, and their
respective agents, employees, officers, directors and managers, including, but not limited to, Contractor, (B)&nbsp;all members, shareholders, partners, limited partners and other Persons that, directly or indirectly, own any interest in Landlord,
(D)&nbsp;all Persons that are owned in whole or in part by Landlord, (E)&nbsp;all of the members of the immediate family of an individual who falls within the scope of subparagraphs (B)&nbsp;or (C) of this section, and (F)&nbsp;all Persons that are
owned, in whole or in part, or controlled by any Person described in subparagraph (E)&nbsp;of this section and all trusts established for the benefit of any such individual or the members of his or her immediate family. As used in the preceding
sentence, the terms &#147;control&#148;, &#147;controlled by&#148; and &#147;under common control with&#148; mean the possession of the power to direct or cause the direction of the management and policies of an entity, whether through the ownership
of voting securities, by contract or otherwise. If any party is comprised of more than one Person, the &#147;Affiliates&#148; of such party shall be the Affiliates of each and every Person comprising the party, jointly and individually. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-4- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxxvii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Landlord&#146;s Work&#148; means all of the
buildings, structures, fixtures, improvements and work set forth in the Final Plans and Specifications and all other work reasonably required to properly complete such buildings, structures, fixtures and improvements and cause the same to be fully
operational in accordance with the Design Requirements. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxxviii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Mechanical Systems&#148;
means the mechanical, electrical, plumbing, heating, air conditioning, elevator, sprinkler and fire protection systems forming a part of the Premises. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xxxix)&nbsp;&nbsp;&nbsp;&nbsp;&#147;MHE Improvements&#148; means (A)&nbsp;substantial completion of the building exterior
precast panels, steel structure with decking, floor slab and roofing for the warehouse area shown as the &#147;Phase I MHE Turnover&#148; and the &#147;Phase II MHE Turnover&#148; on
<B><U><FONT STYLE="white-space:nowrap">Exhibit&nbsp;B-10</FONT></U></B> (collectively, the &#147;MHE Area&#148;), which consists of all the area within column lines&nbsp;1 through 9 and column lines&nbsp;A through N on said <B><U><FONT
STYLE="white-space:nowrap">Exhibit&nbsp;B-10</FONT></U></B>, (B)&nbsp;the MHE Area being in a weather tight condition, (C)&nbsp;completion of two (2)&nbsp;docks, with dock doors and functional dock equipment for use by Tenant, (D)&nbsp;all exterior
window and dock openings being temporarily protected from the elements, (E)&nbsp;all under slab electrical infrastructure, concrete slab on grade, fire protection piping, electrical lighting and any overhead electrical power being installed in the
MHE Area, and temporary electrical power and compressed air being available to the MHE Area, and (F)&nbsp;Landlord&#146;s Work having reached the level of completion necessary to allow Tenant&#146;s MHE Installations to be properly installed, and
reasonably protected. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xl)&nbsp;&nbsp;&nbsp;&nbsp;&#147;MHE Access Date&#148; means the date (A)&nbsp;Landlord completes
the MHE Improvements and (B)&nbsp;irrevocably grants Tenant (in writing) access to the Premises for purposes of staging, installing and testing Tenant&#146;s MHE Installations (as defined in Section&nbsp;3.01(b)) in the MHE Area in accordance with
Section&nbsp;3.01(b) and the right to use at least two (2)&nbsp;loading docks in connection therewith. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xli)&nbsp;&nbsp;&nbsp;&nbsp;&#147;MHE Access Deadline&#148; means July&nbsp;2, 2018, subject to the provisions of
Section&nbsp;3.01 and Section&nbsp;5 of <B><U>Exhibit&nbsp;B</U></B>. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xlii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Milestone
Schedule&#148; means the dates when certain components of the Construction Documents and certain permits and approvals required for the construction of the Project are anticipated to be received, as set forth on
<B><U><FONT STYLE="white-space:nowrap">Exhibit&nbsp;B-5</FONT></U></B>. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xliii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Minor
Deviations&#148; means minor deviations from the Final Plans and Specifications that result from workmanship within normal construction tolerances for Class&nbsp;A industrial and distribution buildings recently built by skilled, experienced and
sophisticated contractors, but not any deviations resulting from a substitution of materials, a change in design, or a failure to install any component of the Final Plans and Specifications. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xliv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Minor Punch List Items&#148; means minor defects and deficiencies in Landlord&#146;s Work
that (A)&nbsp;can be corrected and completed within thirty (30)&nbsp;days of their identification, (B)&nbsp;will cost less than Two Hundred Thousand and No/100 Dollars ($200,000.00), in the aggregate, to remedy, and (C)&nbsp;will not materially
interfere or delay Tenant&#146;s ability to install its furnishing, trade fixtures, equipment and other personal property in the Building, Tenant&#146;s use or occupancy of the Premises for the Permitted Use or the ability to obtain any governmental
permit, license or approval require in connection therewith. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xlv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Monetary Lien&#148; means
any monetary claim, judgment, mortgage, deed of trust, deed to secure debt, security interest or other similar encumbrance. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xlvi)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Monthly Rent&#148; shall have the meaning ascribed to it in Section&nbsp;5.01. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-5- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xlvii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Net Worth&#148; means, with respect to any
Person, the difference between such Person&#146;s total assets and its total liabilities, excluding the amount of any negative goodwill and calculated in accordance with generally accepted accounting principles or other reputable accounting
principles. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xlviii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Permitted Exceptions&#148; means (A)&nbsp;the matters described on
<B><U>Exhibit&nbsp;D</U></B>, (B)&nbsp;reasonable access and utility easements encumbering the Premises entered into by Landlord in accordance with Section&nbsp;3.01(h), (C) any encumbrances caused by Tenant&#146;s affirmative acts, and (D)&nbsp;the
lien for real property taxes that are not yet delinquent. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(xlix)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Permitted Uses&#148; means
any or all of the following purposes and activities related thereto: (A)&nbsp;office uses, general administration, customer service, warehousing, light manufacturing and assembly, distribution, and fulfillment of customer orders; and (B)&nbsp;any
other lawful use. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(l)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Person&#148; means any individual, sole proprietorship, partnership,
limited liability company, joint venture, trust, unincorporated organization, association, corporation, institution or entity, including, without limitation, any governmental body, agency or department. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(li)&nbsp;&nbsp;&nbsp;&nbsp;&#147;PILOT Payments&#148; means the payments in lieu of property taxes to be made with respect to
the Premises under the Incentive Agreements, as the same may be amended from time to time in accordance with Section&nbsp;6.02, including, but not limited to, any annual fees payable to Boone County or any department, official or legal counsel
thereof (including, without limitation, the Treasurer, Assessor, Clerk, Appraiser and Accountant thereof) and any fees payable to the Bond Trustee under the Incentive Agreements. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Premises&#148; means the Land, the Improvements and all rights, interests, privileges,
tenements, hereditaments and easements appurtenant thereto. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(liii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Prohibited Project
Costs&#148; means (A)&nbsp;costs incurred to correct defects in Landlord&#146;s Work, including, but not limited to, defects in design, workmanship, construction or materials and improperly completed work; (B)&nbsp;costs of repairs, maintenance and
replacements covered by warranties or guaranties; (C)&nbsp;depreciation and similar <FONT STYLE="white-space:nowrap">&#147;non-cash&#148;</FONT> costs; (D)&nbsp;reserves; (E) income taxes, gross receipt taxes, profit taxes, estate taxes, succession
taxes, transfer taxes, indebtedness taxes, mortgage taxes, gift taxes, franchise taxes, excise taxes, corporate taxes, partnership taxes, or taxes arising due to the business operations of Landlord, except for indebtedness taxes due in connection
with the Construction Loan and transfer taxes paid by Landlord in connection with its acquisition of the Land; (F)&nbsp;fines, penalties, default interest and late charges; (G)&nbsp;costs associated with the assessment, monitoring, <FONT
STYLE="white-space:nowrap">clean-up,</FONT> removal, abatement or remediation of Hazardous Substances released by Landlord, any of the Landlord Related Parties or any of their respective Affiliates, agents, employees, contractors, subcontractors,
guests or invitees; (H)&nbsp;costs arising as a result of Landlord&#146;s or any of its Landlord Parties&#146; breach of an agreement, negligence, misconduct or violation of Applicable Laws; (I)&nbsp;costs of correcting any <FONT
STYLE="white-space:nowrap">non-compliance</FONT> with Applicable Laws or defects in Landlord&#146;s Work; (J)&nbsp;costs incurred to restore damage caused by fire or other casualty, excluding insurance deductibles; (K)&nbsp;costs of restoring damage
caused by a taking of any portion of the Project by condemnation or eminent domain; (L)&nbsp;refundable amounts and amounts with respect to which Landlord is entitled to reimbursement under any warranty or other agreement; (M)&nbsp;amounts paid to
Landlord or any of the Landlord Parties, except the Development Fee, the Contractor&#146;s Fee, the Landlord&#146;s Permitted Equity Return, and any other amount expressly approved, in writing, by Tenant after the Effective Date, which approval may
be granted or withheld by Tenant in its sole and absolute discretion; (N)&nbsp;costs pertaining to the overhead and <FONT STYLE="white-space:nowrap">off-site</FONT> operations of Landlord or any of the Landlord Parties, including, without
limitation, employee wages, benefits or other compensation, advertising and marking costs, rent, utility costs, insurance costs, accounting charges, and </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-6- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
costs associated with the formation, operation and internal organization of Landlord as a business entity, except for the General Conditions Costs expressly permitted under Sections&nbsp;2(h) and
2(i) of <B><U>Exhibit&nbsp;B</U></B>; (O)&nbsp;costs related to the any real property other than the Project or the operation, maintenance or repair thereof, excluding any costs associated with <FONT STYLE="white-space:nowrap">off-site</FONT> work
included in the Final Plans and Specifications, which the parties expressly agree shall be included; (P)&nbsp;costs of defending or prosecuting any mediation, arbitration proceeding or litigation, including, without limitation, attorneys&#146; fees,
expert fees, court costs, mediator or arbitrator fees and other expenses; (Q)&nbsp;costs incurred in connection with the raising of any capital (debt or equity) other than the Construction Loan, including, but not limited to, cost of selling or
syndicating any interests in Landlord or any of its Affiliates, broker fees, investment advisor fees, marketing costs, attorneys fees&#146;, registration fees, preferred returns, commitment fees, asset management fees, and accounting fees;
(R)&nbsp;charitable or political contributions; (S)&nbsp;refundable amounts; (T)&nbsp;rental costs for machinery and equipment, including repairs to such machinery and equipment, except to the extent expressly provided in the other provisions of
this Lease; (U)&nbsp;the cost of any item not specifically and expressly identified as a Project Cost in this Lease; (V)&nbsp;costs that would cause the Guaranteed Maximum Project Costs to be exceeded, as adjusted in accordance with the terms of
this Lease; (W)&nbsp;costs and fees of attorneys, accountants, or other consultants, unless expressly authorized under the terms of this Lease; (X)&nbsp;any item included in the General Conditions Costs to the extent such costs were included in
Project Costs initially; and (Y)&nbsp;any costs related to upgrading the roof depicted in the Design Requirements to a sixty (60)&nbsp;mil membrane and the purchase of an additional five (5)&nbsp;years of warranty for the roof, thereby bringing the
roof warranty period to twenty-five (25)&nbsp;years (it is anticipated the cost of such upgrade and warranty will be approximately $95,000.00, will be paid by Landlord with its own funds, and will not be included in Project Costs). </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(liv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Project Costs&#148; means all hard and soft costs that are reasonably and necessarily
incurred, paid and documented by Landlord to purchase the Land, design the Project, and construct the Landlord&#146;s Work as allowable under <B><U>Exhibit&nbsp;B</U></B>, excluding Prohibited Project Costs, but including, without limitation,
(A)&nbsp;the cost of purchasing, developing and constructing the building, parking areas, access drives, utility facilities and other improvements detailed in the Final Plans and Specifications, including, without limitation, the cost of <FONT
STYLE="white-space:nowrap">off-site</FONT> work required therein that is completed by Landlord, (B)&nbsp;the architect&#146;s and engineer&#146;s fees incurred by Landlord to complete the Final Plans and Specifications and to perform any necessary
Construction Administration services, (C)&nbsp;the cost of all governmental permits, licenses and other approvals required for the construction of Landlord&#146;s Work, including, without limitation, costs arising from delays in receiving any
permits from governmental entities necessary to perform Landlord&#146;s Work, (D)&nbsp;amounts Landlord is required to pay in connection with the Incentive Agreements under Section&nbsp;2.02, including, without limitation, additional costs
associated with negotiating and entering into any of the Incentive Agreements, fees owed by Landlord under the Incentive Agreement, and fees paid to Landlord&#146;s internal and external legal counsel to review, negotiate or implement the Incentive
Agreements, provided such fees paid to internal and external legal counsel shall not exceed Thirty-Five Thousand and No/100 Dollars ($35,000.00) in the aggregate, (E)&nbsp;impact fees and utility tap, capacity or connection charges resulting from
the development of the Project (including, but not limited to, Landlord&#146;s Work), (F) interest paid by Landlord on the Construction Loan to the extent the proceeds of the Construction Loan are used to pay costs that may be included in Project
Costs under the other provisions of this section, (G)&nbsp;Property Taxes paid by Landlord that are allocable to the period between the Closing Date and the Rent Commencement Date, (H)&nbsp;reasonable attorneys&#146; fees and transaction costs paid
by Landlord in connection with the Construction Loan, including, but not limited to, loan commitment fees, premiums for any lender&#146;s policy of title insurance, recording costs, and indebtedness taxes, (I)&nbsp;the cost of insurance and bonds
obtained by Landlord that are directly related to the construction of Landlord&#146;s Work, (J)&nbsp;the cost of due diligence materials and inspections incurred by Tenant that are paid by Landlord, (K)&nbsp;the cost of any environmental
assessments, abatements or other inspections of the Land obtained by Landlord in connection with its acquisition thereof, except to the extent the same are Prohibited Project Costs, (L)&nbsp;the cost of landscaping, irrigation, signage, utilities,
and </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-7- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
other amenities included in the Final Plans and Specifications, (M)&nbsp;the amount of the brokerage fees paid by Landlord pursuant to Section&nbsp;26.08, (N) any amount Landlord pays Tenant to
reimburse Tenant for the fees paid to Bradley Arant Boult Cummings LLP pursuant to Section&nbsp;26.08, (O) any other hard or soft costs agreed by the parties, in writing, and (P)&nbsp;the Development Fee, the Contractor&#146;s Fee and the
Landlord&#146;s Permitted Equity Return. Notwithstanding anything to the contrary, in no event shall Project Costs include Prohibited Project Costs. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Property Taxes&#148; means (A)&nbsp;ad valorem real property taxes, governmental assessments
(general and special) and governmental storm water fees (but not impact, tap, connection or capacity charges) levied against the Premises; and (B)&nbsp;PILOT Payments. Property Taxes shall not include, and Landlord&#146;s shall be solely responsible
for paying: any income taxes, sales taxes, estate taxes, succession taxes, transfer taxes, indebtedness taxes, gift taxes, inheritance taxes, franchise taxes, excise taxes or special assessments; any impact fees, traffic mitigation fees, highway
fees, signage fees, parking fees, or utility tap, capacity or connection charges resulting from the development of the Premises (including, but not limited to, Landlord&#146;s Work) or any impacts thereof; and any taxes arising due to the business
operations of Landlord. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lvi)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Purchase Agreements&#148; means (A)&nbsp;that certain Real
Estate Option Agreement dated December&nbsp;31, 2016, as amended by that certain undated Real Estate Option Extension Agreement, by and between American Outdoor Brands Corporation, as buyer, and Green Acre Estates, L.L.C., as seller, and
(B)&nbsp;that certain Contract for Sale of Vacant Land dated July&nbsp;12, 2017, by and between American Outdoor Brands Corporation, as buyer, and Last Enterprises, LLC, as seller. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lvii)&nbsp;&nbsp;&nbsp;&nbsp; &#147;Rent&#148; means the Monthly Rent and additional rent that Tenant is expressly required to
pay Landlord under this Lease. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lviii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Rent Adjustment Dates&#148; means (A)&nbsp;the first
(1<SUP STYLE="font-size:85%; vertical-align:top">st</SUP>) day of the twelfth (12<SUP STYLE="font-size:85%; vertical-align:top">th</SUP>) full calendar month following the month in which the Rent Commencement Date occurs (the &#147;Initial
Adjustment Date&#148;), and (B)&nbsp;each anniversary of the Initial Adjustment Date during the Initial Term, but excluding any anniversary of the Initial Adjustment Date during an Extension Period. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lix)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Rent Commencement Date&#148; means, subject to the other terms hereof, the later of
(A)&nbsp;the date that is thirty (30)&nbsp;days after the Delivery Date, or (B)&nbsp;the date that is one hundred seventeen (117)&nbsp;days after the MHE Access Date; or (C)&nbsp;November&nbsp;1, 2018. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lx)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Schedule of Time&#148; means the schedule for completion of Landlord&#146;s Work attached as
<B><U><FONT STYLE="white-space:nowrap">Exhibit&nbsp;B-8</FONT></U></B>. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lxi)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Substantial
Completion&#148; shall mean the occurrence of all of the following: (A)&nbsp;the completion of Landlord&#146;s Work in strict accordance with the Final Plans and Specifications, except for Minor Deviations and Minor Punch List Items; (B)&nbsp;the
issuance of a Certificate of Substantial Completion (AIA G704 Form) to Tenant for Landlord&#146;s Work, which has been signed by Landlord, Architect and Contractor and reflects that Landlord&#146;s Work has been completed in strict accordance with
the Final Plans and Specifications, except for Minor Deviations and Minor Punch List Items; (C)&nbsp;the issuance of a conditional or temporary certificate of occupancy for the Premises by Boone County, Missouri and all other governmental permits,
licenses, approvals, inspection reports, certificates and other documents by applicable governmental authorities required for Tenant to occupy the Premises; (D)&nbsp;the satisfactory <FONT STYLE="white-space:nowrap">start-up,</FONT> testing and
operation of the heating and air conditioning system, mechanical system, electrical system, plumbing system and elevator(s), including, but not limited to, the issuance of a test report for such heating and air conditioning system showing the same
is properly operating and properly balanced, and the Premises being fully energized; (E)&nbsp;the Building being watertight and weathertight; (F) </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-8- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
all known defects and deficiencies in the Landlord&#146;s Work having been corrected, except for Minor Deviations and Minor Punch List Items; (G)&nbsp;all rubbish, tools, scaffolding and surplus
construction materials related to Landlord&#146;s Work having been removed from the Premises; and (H)&nbsp;Landlord&#146;s delivery to Tenant of a fully executed copy of the Memorandum of Lease described in Section&nbsp;26.16 that has been properly
recorded in the Office of the Recorder of Deeds for Boone County, Missouri. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lxii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Tenant
Default&#148; shall have the meaning ascribed to it in Section&nbsp;16.02. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lxiii)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Tenant
Delay&#148; means the actual net delays in substantial completion of the Landlord&#146;s Work to the extent attributed to (A)&nbsp;early access to the Premises by Tenant or any of its agents, employees, contractors or representatives prior to the
Delivery Date, except to the extent caused, in whole or in part, by Landlord&#146;s failure to comply with the terms of this Lease; or (B)&nbsp;affirmative acts of Tenant or any of its agents, employees, contractors or representatives at the
Premises in violation of this Lease, including, without limitation, Tenant&#146;s failure to respond to requests for approval of the Construction Documents within the timeframes set forth in <B><U>Exhibit&nbsp;B</U></B>. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lxiv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Tenant Lease Guarantor&#148; means any Person who, at the time in question, is guaranteeing
the satisfaction of all or a portion of Tenant&#146;s obligations and liabilities under this Lease. As of the Effective Date, the Tenant Lease Guarantor is American Outdoor Brands Corporation. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(lxv)&nbsp;&nbsp;&nbsp;&nbsp;&#147;Term&#148; means the term of this Lease, as the same may be extended or early terminated
pursuant to the provisions of this Lease or any other written agreement entered into by Landlord and Tenant. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">1.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Construction</U>. Unless the context indicates otherwise, (i)&nbsp;the terms
&#147;hereof&#148;, &#147;hereunder,&#148; &#147;herein&#148; and similar expressions refer to this Lease as a whole and not to any particular article, section or paragraph, (ii)&nbsp;the singular includes the plural and the masculine gender
includes the feminine and neuter, and (iii)&nbsp;all references to articles, sections and subsections refer to the articles, sections and subsections of this Lease. The titles of the articles, sections and subsections of this Lease are for
convenience only and shall not affect the meaning of any provision hereof. Landlord and Tenant have agreed to the particular language of this Lease, and any question regarding the meaning of this Lease shall not be resolved by a rule providing for
interpretation against the party who caused the uncertainty to exist or against the draftsman. FOR PURPOSES OF THIS LEASE, TIME SHALL BE CONSIDERED OF THE ESSENCE. </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE II </U></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>DEMISE AND
MASTER LEASE </U></P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">2.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Demise</U>. Landlord hereby leases the Premises to Tenant during the
Term, and Tenant hereby leases the Premises from Landlord during the Term, upon the terms and conditions set forth in this Lease. Tenant shall have access to the Premises twenty-four (24)&nbsp;hours per day, seven (7)&nbsp;days per week, throughout
the Term, and Tenant shall determine the Building&#146;s hours of operation. The Premises shall be exclusively occupied by Tenant and parties claiming by, through or under Tenant, and, subject to the Permitted Exceptions, Landlord shall not
authorize or permit any other Person to use or occupy the same, including, but not limited to, any parking areas, access drives, sidewalks, signage, detention ponds, or utility facilities forming a part of the Premises. Tenant shall have the benefit
of all rights, privileges, tenements, hereditaments and easements forming a part of or appurtenant to the Premises during the Term, including, but not limited to, those under the Permitted Exceptions, and Landlord shall not amend, modify, waive,
terminate, exercise, or grant any consent, forbearance or concession with respect to the same during the Term without Tenant&#146;s prior written approval, which shall not be unreasonably withheld, conditioned, or delayed. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-9- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">2.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Incentives&nbsp;&amp; Prime Lease</U>.</P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;Upon closing of the Ch. 100 bond financing in accordance with the Incentive Agreements, Landlord
shall convey good and marketable fee simple title to the Premises to the County, subject only to the Permitted Exceptions, and enter into the Incentive Agreements related to the Ch. 100 bond financing, all in accordance with the terms of the
Incentive Memorandum. Landlord agrees to: (i)&nbsp;take all actions, and cause the Contractor and its subcontractors to take all actions, necessary to realize the benefit of the sales taxes incentives outlined in the Incentive Memorandum and/or the
Incentive Agreements; (ii)&nbsp;satisfy all of its obligations under this Lease and the Incentive Agreements necessary to effectuate and maintain the incentives outlined in the Incentive Memorandum and/or the Incentive Agreement and comply
therewith, including, without limitation, submitting any necessary certificates; and (iii)&nbsp;use commercially reasonable efforts to otherwise effectuate and maintain such incentives, provided Landlord shall not be required to pay any costs
pursuant to this subparagraph (iii)&nbsp;that are not its obligation under the other provisions of this Lease, unless Tenant agrees, in writing, to reimburse Landlord for the same. Without limiting the generality of the foregoing, Landlord shall pay
all amounts owed to the County under the Incentive Agreements and all attorneys&#146; fees incurred by the County in connection with the preparation or negotiation of the Incentive Agreements or the consummation of the incentives set forth therein,
provided, all such amounts shall be included in Project Costs to the extent the same are due and payable prior to Delivery Date. Landlord shall comply with all of the terms and conditions set forth in the Incentive Agreements that are applicable to
Landlord prior to the Delivery Date and any other obligations that Landlord is required to satisfy under the terms of this Lease, including, but not limited to, paying all rent and other amounts owed by Landlord under the Prime Lease, when due. In
addition, Landlord shall satisfy all of its obligations under the Incentive Agreements arising out of or related to Landlord&#146;s Work, including, without limitation, delivery of the completion certificate required upon Substantial Completion of
Landlord&#146;s Work. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;Each party (the &#147;Indemnifying Party&#148;) shall indemnify, defend
and hold harmless the other party from and against all third party claims (including, but not limited to, claims by Boone County) and resulting liabilities arising or resulting from the Indemnifying Party&#146;s violation of the Incentive
Agreements. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(c)&nbsp;&nbsp;&nbsp;&nbsp;As part of the Incentive Agreements, Landlord and the County will enter into a
lease agreement in the form attached hereto as <B><U>Exhibit&nbsp;E</U></B> (the &#147;Prime Lease&#148;), pursuant to which the Premises will be leased back to Landlord. The parties acknowledge and agree that this Lease will be subordinate to the
Prime Lease throughout the term thereof. Except as provided in Section&nbsp;2.02(e), neither Landlord nor Tenant shall amend, modify, waive any provisions of, terminate, or grant any consent, forbearance or concession with respect to the Prime Lease
during the Term without the other party&#146;s prior written approval, which approval shall not be unreasonably withheld, qualified or delayed by Landlord or Tenant, as applicable, so long as such amendment, modification, waiver, termination or
grant does not materially increase its obligations or liabilities under the Incentive Agreements, excluding any obligations or liabilities that Tenant expressly agrees, in writing, to satisfy. Landlord shall exercise the purchase option granted to
Landlord under Section&nbsp;11.1 of the Prime Lease (the &#147;Purchase Option&#148;) at the end of the term of the Prime Lease, as the same is extended by Tenant in accordance with Section&nbsp;2.02(e) below, without obtaining Tenant&#146;s
consent. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(d)&nbsp;&nbsp;&nbsp;&nbsp;As part of the incentives related to the Project, the County and the State of
Missouri (the &#147;State&#148;) have procured funds from a Community Development Block Grant to fund certain <FONT STYLE="white-space:nowrap">off-site</FONT> improvements, including, but not limited to, a water line serving the Premises. In the
event the County or State fails to install such water line within a time frame that will allow Landlord to achieve Substantial Completion by the Delivery Deadline, then Landlord may, at its option, install such water line
</P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-10- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
at its expense, in which case the amount of the Guaranteed Maximum Project Costs shall be increased by the reasonable
<FONT STYLE="white-space:nowrap"><FONT STYLE="white-space:nowrap">out-of-pocket</FONT></FONT> costs that Landlord incurs to install such water line. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(e)&nbsp;&nbsp;&nbsp;&nbsp;Tenant shall have the right to extend the term of the Prime Lease in connection with the extension
of any incentives granted under the Incentive Agreements (including, without limitation, any extension of the PILOT Payments) or the granting of any new incentives to Tenant under Ch. 100 (collectively, the &#147;New Incentives&#148;). Landlord
agrees to enter into any such extension of the Prime Lease, upon Tenant&#146;s written request; provided, Landlord continues to have the right to purchase the Premises at the end of the term of the Prime Lease, as extended, under the Purchase
Option. In addition, Landlord agrees to enter into amendments, modifications and supplements to the Incentive Agreements required in connection with any such extension of the Prime Lease or New Incentives, upon Tenant&#146;s request; provided, the
same do not materially increase Landlord&#146;s obligations or liabilities under the Incentive Agreements, except for obligations or liabilities that Tenant expressly agrees, in writing, to satisfy. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">2.03&nbsp;&nbsp;&nbsp;&nbsp;<U>Excess Land</U>. Prior to Substantial Completion, Landlord shall convey the portion of the
Premises described on <B><U>Exhibit&nbsp;F</U></B> (the &#147;Excess Land&#148;) to Tenant in accordance with this section; provided, if there is a material adverse change affecting the Excess Land (including, but not limited to, any material
adverse change in the physical condition of the Excess Land not provided for in the Final Plans and Specifications (as subsequently modified by Change Order), title to the Excess Land, or the environmental condition of the Excess Land) prior to such
conveyance, Tenant may elect not to have the Excess Land conveyed to it. Landlord shall give Tenant at least sixty (60)&nbsp;days advance written notice of the date upon which Landlord intends to convey the Excess Land to Tenant pursuant to this
section (the &#147;Excess Land Conveyance Date&#148;). Tenant shall have the right to: (i)&nbsp;inspect the Excess Land, from time to time; (ii)&nbsp;obtain an updated title insurance commitment, survey, and Phase I and Phase II environmental
assessments of the Excess Land; and (iii)&nbsp;review any and all information related to the Excess Land in Landlord&#146;s possession or control. Landlord agrees to cooperate and assist with Tenant&#146;s efforts to obtain a Phase I and Phase II
environmental assessment of the Excess Land, and Landlord shall furnish information reasonably required in connection therewith to the extent in its possession or control. Tenant acknowledges that Landlord intends to mine fill from the Excess Land
as required by the Final Plans and Specifications and that mining such fill will change the physical characteristics of the Excess Land from the condition in which it exists as of the Effective Date to the condition provided for in the Final Plans
and Specifications and this section. Such changes do not constitute a material adverse change for purposes of this Section&nbsp;2.03 so long as the same are consistent with the Final Plans and Specifications and this section. Except for such
changes, Landlord will not make any Alterations to the Excess Land, and Landlord shall cause the areas disturbed as a result of the mining of fill material in accordance with the Final Plans and Specifications to be (i)&nbsp;placed in a condition
that complies with Applicable Laws, (ii)&nbsp;sloped in a manner that reasonably protects against erosion and does not result in any unsafe grades or precipices, and (iii)&nbsp;properly seeded with grass overlaid by straw. In addition, Landlord
shall not place any debris, spoils or other material therein, except clean soil properly compacted in a manner approved by Tenant, which approval shall not be unreasonably withheld. Landlord shall promptly notify Tenant, in writing, if Landlord
learns of any event, matter or circumstance that has or could have a material adverse effect on the Excess Land, including, without limitation, the presence of any Hazardous Substances on, under or about the Excess Land or released therefrom.
Subject to the other terms hereof, Landlord shall convey the Excess Land to Tenant on the Excess Land Conveyance Date, pursuant to this section, by properly executing and delivering to Tenant a Special Warranty Deed conveying good and marketable fee
simple title to the Excess Land to Tenant, subject only to the Permitted Exceptions that encumber the Excess Land (but not others) and free and clear of all Monetary Liens. The Excess Land will not be subject to the Prime Lease. At the time Landlord
delivers such deed to Tenant, Landlord shall also (i)&nbsp;execute and deliver to Tenant&nbsp;an owner&#146;s affidavit, in form and content, sufficient to have the mechanics&#146; and materialmen&#146;s lien exception, rights of parties in
possession </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-11- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
exception and any other standard exceptions removed from the Owner&#146;s Title Policy and the gap insured; (ii)&nbsp;furnish Tenant with evidence, reasonably satisfactory to Tenant and its title
insurance company, that Landlord is duly authorized and empowered to convey the Excess Land to Tenant and perform its other obligations hereunder, including, but not limited to, formation documents, resolutions and certificates of good standing;
(iii)&nbsp;execute and deliver&nbsp;to Tenant all other documents, instruments, certificates and affidavits necessary to consummate the transaction contemplated by this section, including, without limitation, an IRS&nbsp;&#167;1445 certificate; and
(iv)&nbsp;cause all liens (including, without limitation, all Fee Mortgages) affecting the Excess Land to be released and discharged, except for any liens arising or resulting directly from Tenant&#146;s affirmative acts. Tenant shall be responsible
for up to Twenty-Five Thousand and No/100 Dollars ($25,000.00) of the <FONT STYLE="white-space:nowrap"><FONT STYLE="white-space:nowrap">out-of-pocket</FONT></FONT> closing costs incurred by Landlord in conveying the Excess Land to Tenant, including,
without limitation, the cost of subdividing the Excess Land (if required) and all transaction costs in consummating such closing; provided, (i)&nbsp;Landlord shall be responsible for the cost of releasing any Fee Mortgages and other Monetary Liens,
such costs shall be paid by Landlord and shall not be included in Project Costs, and (ii)&nbsp;Landlord shall provide Tenant with reliable evidence of the amount of such costs and the payment thereof, including, but not limited to, invoices and paid
receipts. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE III </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>LANDLORD&#146;S WORK </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">3.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Completion of Landlord&#146;s Work</U>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;Landlord shall cause Landlord&#146;s Work to be completed in accordance with the terms of this
Lease (including, without limitation, <B><U>Exhibit&nbsp;B</U></B>), and Landlord shall comply with all of the terms and conditions of, and satisfy all of its obligations under, <U><B>Exhibit&nbsp;B</B></U>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;Landlord shall deliver possession of the Premises to Tenant promptly following Substantial
Completion; provided, Landlord shall permit Tenant to enter upon and occupy the Premises on the MHE Access Date for purposes of storing, installing and testing Tenant&#146;s material handling equipment, racking systems, and related systems and
equipment (collectively, &#147;Tenant&#146;s MHE Installations&#148;) in accordance with the terms of this section. Tenant shall have possession of the MHE Area from and after the MHE Access Date, except (i)&nbsp;Landlord may use the portion of the
MHE Area identified as the &#147;Phase II MHE Turnover&#148; on <B><U><FONT STYLE="white-space:nowrap">Exhibit&nbsp;B-10</FONT></U></B> (the &#147;Phase&nbsp;II MHE Area&#148;) until the date (the &#147;Phase&nbsp;II MHE Turnover Date&#148;) that is
<FONT STYLE="white-space:nowrap">twenty-one</FONT> (21)&nbsp;days after the MHE Access Date to the extent reasonably necessary to complete Landlord&#146;s Work therein, and (ii)&nbsp;Tenant shall not use the Phase&nbsp;II MHE Area until the Phase II
MHE Turnover Date. During the period between the MHE Access Date and the Phase&nbsp;II MHE Turnover Date, Landlord and Tenant shall each use reasonable efforts not to interfere with the other party&#146;s use of said Phase&nbsp;II MHE Area for the
purposes permitted hereunder. Landlord shall vacate the Phase&nbsp;II MHE Area and deliver possession thereof by the Phase&nbsp;II MHE Turnover Date. Landlord shall deliver possession of the IT Room in IT Room Ready Condition by the IT Room Delivery
Date. Once possession of any portion of the Premises is delivered to Tenant pursuant to this section, Tenant shall have the exclusive right to occupy and control the same. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(c)&nbsp;&nbsp;&nbsp;&nbsp;If the Delivery Date occurs prior to the Delivery Deadline, then Tenant may, at its option, elect
to postpone delivery of the Premises and the Delivery Date until the Delivery Deadline or any date prior thereto upon written notice to Landlord. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(d)&nbsp;&nbsp;&nbsp;&nbsp;Landlord shall give Tenant at least thirty (30)&nbsp;days advanced written notice of: (i)&nbsp;the
date upon which substantial completion of the MHE Improvements will occur; and (ii)&nbsp;the date (the &#147;Projected Delivery Date&#148;) upon which the Delivery Date will occur. Unless Tenant agrees otherwise, in
</P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-12- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
writing, Landlord shall not deliver possession of the Premises to Tenant prior to the Projected Delivery Date. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(e)&nbsp;&nbsp;&nbsp;&nbsp;Subject to Section&nbsp;3.01(g), the MHE Access Deadline shall be extended by the period of any
actual delay in completion of the MHE Improvements caused by an Event of Force Majeure; provided, (i)&nbsp;Landlord shall use commercially reasonable efforts to minimize the duration of such delays, (ii)&nbsp;the MHE Access Deadline shall not be
extended by more than ninety (90)&nbsp;days, in the aggregate, pursuant to this Section&nbsp;3.01(e), except if the MHE Improvements are damaged by insured casualty prior to the MHE Access Deadline, then the MHE Access Deadline shall be extended by
the period of any reasonable delay in completing construction of MHE Improvements caused by such casualty, and (iii)&nbsp;Landlord must notify Tenant, in writing, of any delay in completion of the MHE Improvements caused by an Event of Force Majeure
within thirty (30)&nbsp;days of the occurrence of such Event of Force Majeure. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(f)&nbsp;&nbsp;&nbsp;&nbsp;Subject to
Section&nbsp;3.01(g), the Delivery Deadline shall be extended by the period of any delay in completion of Landlord&#146;s Work caused by an Event of Force Majeure or Tenant Delay; provided, (i)&nbsp;Landlord shall use commercially reasonable efforts
to minimize the duration of such delays, (ii)&nbsp;the Delivery Deadline shall not be extended by more than ninety (90)&nbsp;days, in the aggregate, pursuant to this Section&nbsp;3.01(f), except if the Landlord&#146;s Work is damaged by insured
casualty prior to the Delivery Date, then the Delivery Deadline shall be extended by the period of any reasonable delay in completing construction of Landlord&#146;s Work caused by such casualty, (iii)&nbsp;Landlord must notify Tenant, in writing,
of any delay in completion of the Landlord&#146;s Work caused by an Event of Force Majeure within thirty (30)&nbsp;days of the occurrence of such Event of Force Majeure, and (iv)&nbsp;Landlord must notify Tenant, verbally and in writing, of any
delay in the completion of Landlord&#146;s Work caused by a Tenant Delay within forty-eight (48)&nbsp;hours after the occurrence of such Tenant Delay so that Tenant may cure the same. Landlord shall notify Tenant of the actual number of days of
delay associated with any Tenant Delay within five (5)&nbsp;days of resolution of any Tenant Delay. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(g)&nbsp;&nbsp;&nbsp;&nbsp;Notwithstanding anything to the contrary contained herein, if Landlord fails to notify Tenant, in
writing, of any delay in the completion of MHE Improvements or Landlord&#146;s Work caused by an Event of Force Majeure within thirty (30)&nbsp;days after the occurrence of such Event of Force Majeure, the MHE Access Deadline and/or the Delivery
Deadline shall not be extended by the period of such delay. Delays in the completion of Landlord&#146;s Work caused by weather conditions shall be considered caused by an Event of Force Majeure if, but only if: (i)&nbsp;Landlord demonstrates that
the weather condition at issue is more severe than one would reasonably expect to encounter at the Land based on historical conditions over the past three (3)&nbsp;years as established by the National Weather Service; (ii)&nbsp;Landlord notifies
Tenant, in writing, of such weather conditions within thirty (30)&nbsp;days after the occurrence thereof; and (iii)&nbsp;such notification identifies the time critical trades which will be or were delayed by the weather condition and the impact on
the Schedule of Time. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(h)&nbsp;&nbsp;&nbsp;&nbsp;Notwithstanding anything to the contrary herein, Landlord may grant the
following easements, without obtaining Tenant&#146;s consent, to the extent they are reasonably necessary for the performance of Landlord&#146;s Work or the development or construction of the Project: (i)&nbsp;easements over, under, through and
across the Premises for utility lines, communications lines, cable television lines, and related facilities exclusively serving the Premises, provided such easements do not materially interfere with Tenant&#146;s ability to use the Premises, such
easements do not materially interfere with, impair or decrease any of Tenant&#146;s rights hereunder, such easements do not materially increase Tenant&#146;s obligations or liabilities hereunder, and such easements do not violate the Incentive
Agreements, any existing Permitted Exceptions or the other terms of this Lease; and (ii)&nbsp;utility easements over, under, through and across Premises for publicly dedicated utility mains and related facilities shown in the Final Plans and
Specifications, provided such easements do not materially interfere with Tenant&#146;s ability to use </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-13- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">the Premises, such easements do not materially interfere with, impair or decrease any of
Tenant&#146;s rights hereunder, such easements do not materially increase Tenant&#146;s obligations or liabilities hereunder, such easements do not violate the Incentive Agreements, any existing Permitted Exceptions or the other terms of this Lease.
</P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(i)&nbsp;&nbsp;&nbsp;&nbsp;In the event the MHE Access Deadline or Delivery Deadline is extended pursuant to Sections
3.01(e) or 3.01(f) above, the Landlord shall also be entitled to an adjustment in the Guaranteed Maximum Project Costs only for those additional General Conditions Costs actually incurred as a result of delay to the critical path activities of the
Landlord&#146;s Work that are permitted under <U><B>Exhibit&nbsp;B</B></U>, but no other damages or costs of any kind, including, without limitation, indirect (e.g., home office overhead costs), incidental, or consequential damages. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">3.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Entry and Inspection</U>. Upon reasonable, advance notice to Landlord, Tenant shall have the
right to enter upon the Premises prior to the Delivery Date for purposes of: (i)&nbsp;inspecting Landlord&#146;s Work and the Premises; and (ii)&nbsp;taking measurements and space planning; provided Tenant shall not materially interfere with the
completion of Landlord&#146;s Work. In addition, Tenant shall have the right to enter the Premises following substantial completion of the MHE Improvements for purposes of storing, installing, and testing Tenant&#146;s MHE Installations. Landlord
shall make commercially reasonable efforts to coordinate the construction of Landlord&#146;s Work following substantial completion of the MHE Improvements with Tenant in order to allow Tenant the ability to install and test Tenant&#146;s MHE
Installations; provided, that (i)&nbsp;Tenant is required to carry its own insurance liability insurance and property insurance in accordance with Section&nbsp;11.01, (ii) Tenant must comply with Landlord&#146;s reasonable safety and security
precautions so long as Landlord has furnished a written copy thereof and such precautions do not materially increase Tenant&#146;s obligations or materially decrease its rights hereunder or materially impair its ability to install Tenant&#146;s MHE
Installations, and (iii)&nbsp;Tenant must use commercially reasonable efforts to maintain labor harmony on site to the extent reasonably requested, in writing and in advance, by Landlord in connection with such early entry and the installation and
testing of Tenant&#146;s MHE Installations. If any of Tenant&#146;s MHE Installations are damaged by Landlord or its agents, employees, contractors or representatives prior to the Delivery Date, Landlord shall promptly notify Tenant of such damage
and Landlord shall cause such damage to be repaired, in a manner reasonably acceptable to Tenant. At all times during Tenant&#146;s use or occupancy of the Premises prior to the Delivery Date, Tenant shall coordinate its activities with Landlord and
Landlord&#146;s contractors and shall provide, prior to such use or occupancy, all required insurance certificates requested by Landlord to evidence the insurance that Tenant is required to maintain hereunder. Landlord shall pay, prior to the
Delivery Date, all impact fees, traffic mitigation fees, highway fees, signage fees, parking fees, tap fees, utility connection charges, and utility capacity charges related to the development of the Premises (including, but not limited to,
Landlord&#146;s Work) or the occupancy thereof. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">3.03&nbsp;&nbsp;&nbsp;&nbsp;<U>Gross Building Area</U>. Within thirty
(30)&nbsp;days after the Delivery Date, Landlord shall furnish Tenant with a written statement signed by the Architect (the &#147;Architect&#146;s Certificate&#148;) certifying the Gross Building Area to Landlord and Tenant. If Tenant disputes the
Gross Building Area set forth in the Architect&#146;s Certificate, Tenant shall notify Landlord, in writing, of such dispute within thirty (30)&nbsp;days after the Rent Commencement Date. In the event Tenant timely disputes the Gross Building Area
set forth in the Architect&#146;s Certificate, Tenant&#146;s representative and Landlord&#146;s representative will endeavor, in good faith, to resolve such dispute within thirty (30)&nbsp;days thereafter. If Landlord and Tenant are unable to
resolve any such dispute regarding the Gross Building Area within such thirty (30)&nbsp;day period, then (i)&nbsp;Landlord shall retain an independent architect reasonably approved, in writing, by Tenant to measure the Building, (ii)&nbsp;such
architect&#146;s determination of the Gross Building Area shall be conclusive and binding on Landlord and Tenant, and (iii)&nbsp;Landlord and Tenant shall each pay <FONT STYLE="white-space:nowrap">one-half</FONT> (1/2) of the fee charged by such
independent architect to measure the Building. In the event that the actual Gross Building Area is greater than the Estimated Gross Building Area, there shall be no adjustment to Monthly Rent. In the
</P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-14- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
event the actual Gross Building Area, as of the Delivery Date, is less than ninety-eight and <FONT STYLE="white-space:nowrap">one-half</FONT> percent (98.5%) of the Estimated Gross Building Area
and Tenant does not require that Landlord correct the discrepancy, then there shall be a reduction in the Monthly Rent calculated by multiplying the Monthly Rent by a fraction whose numerator is the actual Gross Building Area and whose denominator
is the Estimated Gross Building Area (New Monthly Rent = Old Monthly Rent * Actual Gross Building Area / Estimated Gross Building Area). </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">3.04&nbsp;&nbsp;&nbsp;&nbsp;<U>Indemnification</U>. Except to the extent caused by the negligent acts or willful misconduct of
Tenant or any of its agents, employees, contractors or representatives, Landlord shall indemnify, defend (through attorneys reasonably acceptable to Tenant) and hold harmless Tenant and its Affiliates, officers, directors, owners, members, agents
and employees from and against all third party claims and associated lawsuits, damages, losses, liabilities, costs and expenses (including, without limitation, reasonable attorneys&#146; fees actually incurred) arising or resulting from:
(i)&nbsp;Landlord&#146;s construction of the Landlord&#146;s Work or any defects therein; (ii)&nbsp;any negligence or willful misconduct of Landlord or any of its agents, employees, contractors or representatives (including, without limitation,
Contractor and Architect) occurring on the Premises during construction of Landlord&#146;s Work or related to Landlord&#146;s Work; or (iii)&nbsp;any dispute between Landlord and any contractor, subcontractor, supplier or other Person (excluding
Tenant) related to the construction of the Landlord&#146;s Work, including, but not limited to Contractor and Architect. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE IV
</U></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>TERM </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">4.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Term</U>. Subject to the other provisions hereof, the initial term of this Lease (the
&#147;Initial Term&#148;) shall commence on the Delivery Date and expire at midnight on the last day of the two hundred fortieth (240<SUP STYLE="font-size:85%; vertical-align:top">th</SUP>) full calendar month after the month in which the Rent
Commencement Date occurs (the &#147;Initial Term&#148;). Within thirty (30)&nbsp;days after the exact Rent Commencement Date has been determined, Tenant and Landlord shall execute, acknowledge and deliver a written statement, in the form attached
hereto as <B><U>Exhibit&nbsp;G</U></B>, setting forth the Delivery Date, the Rent Commencement Date, the initial Monthly Rent, and the Gross Building Area; provided, if Tenant has disputed the Gross Building Area in accordance with ARTICLE III,
Landlord and Tenant shall execute such statement within thirty (30)&nbsp;days after the Gross Building Area has been conclusively determined pursuant to Section&nbsp;3.03. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">4.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Extension Options</U>. Landlord hereby grants Tenant six (6)&nbsp;extension options (such
options being individually referred to as an &#147;Extension Option&#148; and collectively referred to as the &#147;Extension Options&#148;), each of which, if exercised, shall extend the term of this Lease for an additional five (5)&nbsp;years
(each an &#147;Extension Period&#148;). Tenant may exercise an Extension Option, by giving written notice to Landlord, at any time during the Term or after the end of the Term so long as there is no outstanding Tenant Default; provided, if Tenant
does not exercise an Extension Option by the date that is thirteen (13)&nbsp;months prior to the date the Term is then set to expire, then (i)&nbsp;Landlord may at any time thereafter send a written notice (an &#147;Extension Notice&#148;) to Tenant
reminding Tenant of its rights under this Section&nbsp;4.02, and (ii)&nbsp;Tenant must exercise an Extension Option within thirty (30)&nbsp;days after Tenant&#146;s receipt of said Extension Notice or Tenant will cease to have any right to extend
the Term pursuant to this Section&nbsp;4.02. If Tenant exercises any Extension Option, this Lease shall continue throughout the resulting Extension Period under all of the same terms and conditions hereof, except as otherwise expressly set forth
herein. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-15- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE V </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>MONTHLY RENT </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">5.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Monthly Rent</U>. Commencing on the Rent Commencement Date and continuing throughout the
remainder of the Term, Tenant shall pay Landlord monthly rent (the &#147;Monthly Rent&#148;) for the Premises in accordance with the terms of this section. Subject to the other terms hereof, the Monthly Rent shall be paid, in advance, with the first
installment of Monthly Rent being due ten (10)&nbsp;Business Days after the Rent Commencement Date and with subsequent installments of Monthly Rent being due on the first (1<SUP STYLE="font-size:85%; vertical-align:top">st</SUP>) day of each month
thereafter during the Term. The Monthly Rent shall be prorated for any partial month during the Term. Subject to the other terms hereof, the Monthly Rent initially shall be an amount equal to <FONT STYLE="white-space:nowrap">one-twelfth</FONT> (1/12<SUP
STYLE="font-size:85%; vertical-align:top">th</SUP>) of the product obtained by multiplying: (i)&nbsp;the decimal equivalent of six and <FONT STYLE="white-space:nowrap">one-quarter</FONT> percent (6.25%); by (ii)&nbsp;the lesser of (A)&nbsp;the
Project Costs incurred, paid and documented by Landlord, or (B)&nbsp;the Guaranteed Maximum Project Costs minus the amount of the Unused Allowance Amounts&nbsp;&amp; Restricted Savings (as defined on <B><U>Exhibit&nbsp;B</U></B>). The Monthly Rent
shall be subject to adjustment as expressly provided in this Lease. On each Rent Adjustment Date during the Initial Term, the Monthly Rent shall be increased by one and seventy-five hundredths percent (1.75%). In the event Tenant exercises any
Extension Option, then, in lieu of any increase pursuant to the preceding sentence, the Monthly Rent during the Extension Period resulting from the exercise of such Extension Option shall be determined in accordance with
<B><U>Exhibit&nbsp;H</U></B>. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">5.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Late Charges</U>. If Tenant fails to pay any installment of
Rent due under this Lease within five (5)&nbsp;days after the same is due, then (i)&nbsp;Tenant shall pay Landlord a late charge equal to five percent (5%) of such installment for the purposes of defraying Landlord&#146;s administrative expenses
relative to handling such overdue payment; and (ii)&nbsp;such installment shall bear interest from the date due until paid at the lesser of ten percent (10%) per annum or the maximum rate permitted under Applicable Laws (the &#147;Default
Rate&#148;); provided, no such late fee or interest shall be due with respect to the first (1st) late installment of Rent during any calendar year so long as Tenant pays such late installments of Rent to Landlord within ten (10)&nbsp;days after
Landlord gives Tenant written notice thereof. The parties agree that the provisions of this section are reasonable and shall not be deemed (i)&nbsp;a consent by Landlord to late payments, (ii)&nbsp;a penalty, (iii)&nbsp;a waiver of Landlord&#146;s
right to insist on the timely payment of Rent, or (iv)&nbsp;a waiver or limitation of the rights and remedies available to Landlord on account of the late payment of any Rent. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">5.03&nbsp;&nbsp;&nbsp;&nbsp;<U>Payment</U>. Except as otherwise expressly provided herein, all Rent shall be paid by Tenant
without deduction, demand, notice or offset, in U.S. Dollars, in cash or by check or by wire transfer to an account designated by Landlord; provided, Tenant shall have the right to select which of such methods it uses to tender payment to Landlord.
Tenant shall deliver all Rent to Landlord at the address specified in ARTICLE&nbsp;XXII or such other place as Landlord may designate to Tenant by written notice. The amounts payable by Tenant to Landlord under this Lease are the sole and exclusive
amounts that Tenant owes Landlord in connection with its use and occupancy of the Premises during the Term. In no event shall Landlord charge Tenant any additional amount to use the parking areas forming a part of the Premises. </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE VI </U></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>PROPERTY
TAXES AND INCENTIVES </U></P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">6.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Property Taxes</U>. Landlord represents, warrants and covenants
that the Premises are currently treated as two separate and discrete tax parcels for purposes of all Property Taxes that do not include any other real property or improvements; provided, that Landlord is in the process of completing a lot
combination started by Tenant and will see that process through to completion, after which the Premises, excluding the Excess Land, will be treated as a single tax parcel and the Excess Land will be </P>

 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-16- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
treated a single tax parcel. Subject to the other terms hereof, (i)&nbsp;Tenant shall pay all Property Taxes that are allocable to periods falling within the Term; and (ii)&nbsp;Landlord shall
pay all Property Taxes that are allocable to periods outside the Term. Tenant shall pay <FONT STYLE="white-space:nowrap">one-twelfth</FONT> (1/12th) of Landlord&#146;s reasonable estimate of Tenant&#146;s Share of the Property Taxes for each
calendar year during the Term, on or before the first (1st) day of each month during such calendar year. Landlord shall furnish Tenant with a written statement (a &#147;Property Tax Statement&#148;) showing the calculation of the amounts Tenant owes
under this section for each calendar year during the Term, promptly after the same are known with certainty. If the estimated payments made by Tenant pursuant to this section with respect to any calendar year are not sufficient to cover the portion
of the Property Taxes for such calendar year to be paid by Tenant under this Section&nbsp;6.01, then Tenant shall pay Landlord the deficiency within thirty (30)&nbsp;days after Tenant&#146;s receipt of the Property Tax Statement for such year. If
the estimated payments made by Tenant pursuant to this section with respect to any calendar year exceed the portion of the Property Taxes for such calendar year to be paid by Tenant under this section, then the excess shall be credited against
future amounts Tenant owes under this section; provided any such excess existing at the expiration or termination of this Lease shall be promptly refunded to Tenant. Tenant shall have the right in its own name, or in Landlord&#146;s name where
appropriate, to contest the amount or legality of any Property Taxes with Landlord&#146;s prior written approval, which shall not be unreasonably withheld, conditioned or delayed. Landlord agrees to execute any commercially reasonable instruments
required to allow any such contest, and Landlord agrees to cooperate and assist with any such contest; provided Landlord shall not be required to incur any <FONT STYLE="white-space:nowrap"><FONT STYLE="white-space:nowrap">out-of-pocket</FONT></FONT>
costs in connection therewith. If Tenant contests the amount or legality of any Property Taxes, then, so long as the payment of such Property Taxes may legally be held in abeyance, the time within which Tenant must pay the same shall be extended
until such contest is completed, provided Tenant shall be responsible for any penalty imposed by the taxing authority as a result thereof, and Tenant shall promptly post a bond or other security required by the taxing authority if forfeiture is
threatened. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">6.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Incentive Agreements</U>. Prior to Substantial Completion, Landlord will
comply with the terms of the Incentive Agreements and file all forms and take all actions necessary for Tenant to realize the benefit of the incentives granted under the Incentive Agreements. In addition, Landlord shall cause Contractors and all of
their respective subcontractors, vendors and suppliers furnishing materials, supplies or other items in connection with Landlord&#146;s Work to submit all forms and take all actions necessary for Tenant to realize the benefit of all sales tax
abatements and rebates granted under the Incentive Agreements. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE VII </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>USE AND OPERATION </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">7.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Use</U>. Tenant and its Affiliates, employees, subtenants and licensees shall have the right to
use the Premises for any or all of the Permitted Uses. Tenant may not use the Premises for any purpose other than the Permitted Uses, unless Tenant obtains Landlord&#146;s prior written consent, which consent shall not be unreasonably withheld,
qualified or delayed. Tenant shall conduct its operations and activities on the Premises in material compliance with all Applicable Laws; provided, (i)&nbsp;Tenant shall have the right to contest the enforcement or attempted enforcement of any
Applicable Law, in good faith and with due diligence, (ii)&nbsp;Tenant shall not be deemed to have defaulted under this Lease as a result of its failure to comply with any Applicable Law until a final and unappealable court order against Tenant has
been entered enforcing the same and the period of time reasonably necessary to effect compliance therewith has passed, and (iii)&nbsp;Landlord shall be responsible for causing Landlord&#146;s Work to comply with Applicable Laws. Tenant shall cause
its Alterations (if any) to comply with Applicable Laws. Tenant shall indemnify, defend and hold harmless Landlord from and against any third party claims and associated lawsuits, governmental actions, obligations, liabilities, damages, costs and
expenses (including, without limitation, court costs, litigation expenses and attorneys&#146; fees) caused by Tenant&#146;s </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-17- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
failure to conduct its operations and activities at the Premises in compliance with Applicable Laws. Tenant shall have the right to discontinue its operations in the Premises, in whole or in
part, at any time Tenant determines appropriate, in its sole and absolute discretion. Nothing contained in this Lease shall be deemed to require Tenant to use or occupy the Premises, and Tenant&#146;s vacation of the Premises or failure to use or
occupy the Premises shall not constitute a default hereunder. Notwithstanding Tenant&#146;s election to discontinue its operations at the Premises, Tenant shall not cancel electric or water service to the Premises, Tenant shall keep the parking
lights operational in accordance with its prior practices at the Premises, and Tenant shall cause the Building to be heated and cooled to the extent necessary to prevent material damage thereto (excluding ordinary wear and tear and subject to
disruptions outside Tenant&#146;s reasonable control or resulting from Landlord&#146;s failure to satisfy its obligations hereunder), until the termination of this Lease or Tenant&#146;s right to possession of the Premises. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">7.02&nbsp;&nbsp;&nbsp;&nbsp;<U>No Waste</U>. Tenant shall not commit or allow any waste to be committed on any portion of the
Premises by Tenant or any of its Affiliates, employees, agents, subtenants, contractors or representatives. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">7.03&nbsp;&nbsp;&nbsp;&nbsp;<U>Hazardous Substances</U>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;Tenant may store, use, handle and generate Hazardous Substances at the Premises in connection with
the Permitted Uses in commercial quantities normally associated therewith and in accordance with Applicable Laws. During the Term, Tenant shall be responsible for disposing of all Hazardous Substances generated by Tenant&#146;s operations at the
Premises or its employees, Affiliates, contractors, subtenants and licensees operations at the Premises, at Tenant&#146;s expense. Tenant shall comply with all Applicable Laws in connection with Tenant&#146;s storage, use, handling and generation of
Hazardous Substances at the Premises. Upon the expiration or earlier termination of this Lease, Tenant shall remove all Hazardous Substances being kept on the Premises by Tenant, its employees, Affiliates, contractors, subtenants and licensees, in
accordance with Applicable Laws. Notwithstanding anything to the contrary in this Lease, and in consideration of Tenant&#146;s rights set forth in this Section&nbsp;7.03, Tenant shall indemnify, defend and hold harmless Landlord from and against all
third party claims and associated lawsuits, governmental actions, obligations, liabilities, costs and expenses (including, but not limited to, court costs, reasonable attorneys&#146; fees and remediation costs) caused by Tenant&#146;s or any of its
employee&#146;s, Affiliate&#146;s, subtenant&#146;s or licensee&#146;s release of any Hazardous Substances on, under or about the Premises during the Term in violation of Applicable Laws (any such release being referred to as &#147;Tenant
Contamination&#148;); provided, Tenant Contamination shall not include any such release caused by Landlord or any of Landlord&#146;s Affiliates, employees, agents, contractors or representatives Tenant&#146;s indemnification obligations in this
Section shall include the obligation to defend Landlord, with counsel reasonably satisfactory to Landlord, in any proceedings, all at Tenant&#146;s expense. Tenant&#146;s indemnification obligations under this subsection shall survive the expiration
or earlier termination of this Lease, and shall not be limited by any provisions of this Lease limiting Tenant&#146;s liability hereunder. In the event of Tenant Contamination, Tenant shall only be required to investigate, monitor and <FONT
STYLE="white-space:nowrap">clean-up,</FONT> remove, abate or remediate such Tenant Contamination to the extent validly required by any governmental authority under Applicable Law. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;Landlord shall deliver the Premises to Tenant in compliance with all Applicable Laws, including
environmental laws, and free of any Hazardous Substances that violate Applicable Laws or that are present in quantities that could require additional assessments, <FONT STYLE="white-space:nowrap">clean-up</FONT> or remediation under Applicable
Laws.&nbsp;Without limiting the generality of the foregoing, Landlord shall remove and dispose of all asbestos, asbestos containing material, lead paint and other Hazardous Substances more particularly described in that certain Asbestos and
Hazardous Building Material Survey Report, Proposed Development, North Route&nbsp;Z, Columbia, Missouri, prepared by Amec Foster Wheeler Environment&nbsp;&amp; Infrastructure, Inc. for American Outdoor Brands Corp., dated March&nbsp;29, 2017, and
that certain Asbestos, </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-18- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
Lead Paint and Regulated Materials prepared by Terracon Consultants, Inc., dated October&nbsp;13, 2017 and identified as Phase&nbsp;I Environmental Site Assessment Route&nbsp;Z Parcels,
1800&nbsp;North Route&nbsp;Z, Columbia, Boone County, Missouri.&nbsp;Landlord shall comply with all Applicable Laws, including, without limitation, making required notifications to governmental authorities, in connection with the characterization,
containment, removal, storage, and disposal of any asbestos, asbestos containing material, lead paint or other Hazardous Substances pursuant to this section (collectively, &#147;Existing Hazardous Substances&#148;).&nbsp;Landlord shall cause all
Existing Hazardous Substances removed from the Premises pursuant to this section to be properly characterized and disposed of in accordance with Applicable Laws at a qualified landfill, using only trained and State licensed contractors. Landlord
shall be the signatory to required notifications to governmental authorities, as owner of the Premises, and any shipping papers, including waste disposal manifests, as owner of the Premises and/or generator, in connection with the characterization,
containment, removal, storage, and disposal of Existing Hazardous Substances.&nbsp;Landlord shall deliver copies of all notifications to any governmental authorities, licenses, permits, transportation logs, and waste disposal manifests related to
the removal or disposal of Existing Hazardous Substances to Tenant prior to the Delivery Date. Landlord shall indemnify, defend and hold harmless Tenant from and against all third party claims and associated lawsuits, governmental actions,
obligations, liabilities, costs and expenses (including, but not limited to, court costs, reasonable attorneys&#146; fees and remediation costs) arising out of any violation of this section. Landlord&#146;s indemnification obligations in this
Section shall include the obligation to defend Landlord, with counsel reasonably satisfactory to Landlord, in any proceedings, all at Tenant&#146;s expense. Landlord&#146;s indemnification obligations under this section shall survive the expiration
or earlier termination of this Lease, and shall not be limited by any provisions of this Lease limiting Landlord&#146;s liability hereunder. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(c)&nbsp;&nbsp;&nbsp;&nbsp;Landlord shall not use, store, generate, release or discharge any Hazardous Substances on the
Premises in violation of Applicable Laws, and shall cause the Landlord Related Parties and any employees, Affiliates, contractors, representatives and licensee of Landlord or the Landlord Related Parties not to use, store, generate, release or
discharge any Hazardous Substances on the Premises in violation of Applicable Laws.&nbsp;Landlord shall indemnify, defend and hold harmless Tenant from and against all third-party claims and associated lawsuits, governmental actions, obligations,
liabilities, costs and expenses (including, but not limited to, court costs, reasonable attorneys&#146; fees and remediation costs) caused by Landlord&#146;s, any of the Landlord Related Parties or any of their respective employee&#146;s,
Affiliate&#146;s, contractor&#146;s, representative&#146;s or licensee&#146;s release of any Hazardous Substances on, under or about the Premises during the Term in violation of Applicable Laws (any such release being referred to as &#147;Landlord
Contamination&#148;).&nbsp;Landlord&#146;s indemnification obligations in this Section shall include the obligation to defend Tenant, with counsel reasonably satisfactory to Tenant, in any proceedings, all at Landlord&#146;s
expense.&nbsp;Landlord&#146;s indemnification obligations under this section shall survive the expiration or earlier termination of this Lease, and shall not be limited by any provisions of this Lease limiting Landlord&#146;s liability
hereunder.&nbsp;In the event of Landlord Contamination, Landlord shall investigate, monitor and <FONT STYLE="white-space:nowrap">clean-up,</FONT> remove, abate or remediate such Landlord Contamination to the extent validly required by any
governmental authority under Applicable Law, in a manner that does not materially interfere with Tenant&#146;s use of the Premises and its operations thereon. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(d)&nbsp;&nbsp;&nbsp;&nbsp;Tenant shall not permit undue accumulations of garbage, trash, rubbish or other refuse within the
Premises and shall keep all refuse in proper containers until disposal of such refuse from the Premises. Tenant shall not mix or dispose of any Hazardous Substances with the general office refuse or other
<FONT STYLE="white-space:nowrap">non-regulated</FONT> waste in violation of Applicable Laws. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">7.04&nbsp;&nbsp;&nbsp;&nbsp;<U>Signage</U>. Tenant may install any and all signs, banners and other advertising materials
(collectively, &#147;Tenant&#146;s Signs&#148;) on the Premises (interior and exterior) that are permitted under the Prime Lease, Applicable Laws and the Permitted Exceptions, including, but not limited to, its panel on any pylon or monument sign
installed by Landlord as part of Landlord&#146;s Work, and Tenant shall not be </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-19- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
required to obtain Landlord&#146;s approval of any of Tenant&#146;s Signs. Tenant shall repair any damage to the Premises caused by the installation or removal of the Tenant&#146;s Signs. Tenant
shall perform all maintenance, repairs and replacements required to keep Tenant&#146;s Signs in a good condition. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">7.05&nbsp;&nbsp;&nbsp;&nbsp;<U>Solar / Telecommunications Rights</U>. Tenant shall have the exclusive right to install or
permit the installation of solar and telecommunications equipment, systems and facilities on the Premises, including, without limitation, the roof of the building, and to receive all economic and other benefits
thereof.&nbsp;&nbsp;&nbsp;&nbsp;Notwithstanding the foregoing, Tenant shall not install any equipment on the rooftop pursuant to this section, without Landlord&#146;s prior written consent thereto, which consent shall not be unreasonably withheld,
conditioned, or delayed. If Landlord does not notify Tenant, in writing, of its objections to the installation of any such equipment on the rooftop of the Building within thirty (30)&nbsp;days after Tenant requests Landlord&#146;s approval of the
same, in writing, then Landlord shall be deemed to have approved such installation. It shall not be unreasonable for Landlord to specify which contractors Tenant is required to work with in accordance with Section&nbsp;10.01(c) below, to require
that Tenant repair any damage to the roof caused by Tenant&#146;s installation of any equipment on the roof of the Premises pursuant to this section, and to require that Tenant not void of any roof warranty as a result of Tenant&#146;s installation
of any such equipment pursuant to this section. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE VIII </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>UTILITIES </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">8.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Utility Services</U>. Landlord shall install, or cause to be installed, all utility lines and
related facilities required to properly serve the Premises as part of Landlord&#146;s Work, and Landlord shall ensure that all such utilities are separately metered, are installed in accordance with the Final Plans and Specifications, and are fully
operational as of the Delivery Date. Tenant shall pay directly to the appropriate utility companies for telephone, electricity, gas, water and sewer service provided to the Premises during the Term, provided, unless due to Landlord&#146;s or any of
its agent&#146;s, employee&#146;s, contractor&#146;s or representative&#146;s affirmative act, negligent act, willful misconduct or breach of this Lease, Landlord shall not be liable to Tenant as a result of a disruption of any utility service to
the Premises and any such disruption shall not relieve Tenant of any of its obligations or liabilities under this Lease. If any utility service to the Premises is disrupted to such an extent that Tenant cannot, in its reasonable judgment, use a
material portion of the Premises for a period of more than <FONT STYLE="white-space:nowrap">seventy-two</FONT> (72)&nbsp;hours due to Landlord&#146;s or any of its agent&#146;s, employee&#146;s, contractor&#146;s or representative&#146;s affirmative
act, negligent act, willful misconduct or breach of this Lease, then the Rent shall abate in proportion to the area of the Premises rendered unusable by such disruption during the entire period of such disruption. Landlord hereby represents and
warrants to Tenant that as of the Delivery Date, water, sewer, electricity, gas, telephone and internet service will be available at the Premises, in capacities set forth on the Final Plans and Specifications. </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE IX </U></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>MAINTENANCE
AND REPAIR </U></P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">9.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Landlord Repairs</U>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;Throughout the Term, Landlord shall diligently perform all repairs, maintenance and replacements
required to keep the roof, foundation, floor slab, structural elements and exterior walls of the Premises in compliance with the Incentive Agreements and in a good, clean and safe condition, in proper working order at all times; except
(i)&nbsp;Tenant shall be responsible for normal preventive maintenance of the roof of the Building to the extent expressly provided in Section&nbsp;9.02, and (ii)&nbsp;Tenant shall be responsible for repairing the roof membrane and roof insulation
as expressly provided in Section&nbsp;9.02 (excluding the roof deck and trusses) from and after the end of the first (1<SUP STYLE="font-size:85%; vertical-align:top">st</SUP>) Extension Period if </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-20- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
Tenant exercises the second (2<SUP STYLE="font-size:85%; vertical-align:top">nd</SUP>) Extension Option and the Term is extended as a result thereof. In addition, Landlord shall cause the
Premises to comply with Applicable Laws as of the Delivery Date, including, but not limited to, the Americans with Disabilities Act, 42&nbsp;U.S.C. &#167;&nbsp;12101, et seq., or any successor thereto. All repairs, maintenance and replacements to be
made by Landlord under this Lease shall be completed in a good and workmanlike manner, in compliance with all Applicable Laws, and consistent with (or better than) the initial quality of Landlord&#146;s Work. Landlord shall use its best efforts to
perform all maintenance, repairs and replacements that are Landlord&#146;s responsibility under this Section&nbsp;9.01 in a manner that does not materially interfere with Tenant&#146;s use and enjoyment of the Premises. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;Landlord shall use reasonable efforts to enforce all manufacturer, supplier, contractor,
subcontractor and other warranties and guaranties related to Landlord&#146;s Work; provided if Landlord fails to enforce any such warranties or guaranties, Tenant may (but shall not be obligated to) enforce the same and Landlord shall cooperate,
assist and join in such efforts. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(c)&nbsp;&nbsp;&nbsp;&nbsp;If any repairs, maintenance or replacements are required to
the roof, foundation, structural elements, floor slab or exterior walls of the Building as a result of damage to the Premises caused by Tenant or its Affiliates, agents, employees, contractors or representatives, excluding ordinary wear and tear and
damage that is subject to the waiver set forth in Section&nbsp;11.04, then Tenant shall reimburse Landlord for the third party actual, verifiable and reasonable cost of such repairs, maintenance or replacements, within sixty (60)&nbsp;days of
Tenant&#146;s receipt of a written demand for the same from Landlord, accompanied by reliable evidence of the costs for which reimbursement is sought. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">9.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Tenant Repairs</U>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;Except for portions of the Premises that Landlord is required to maintain, repair and replace under
Section&nbsp;9.01(a), Section&nbsp;9.01(b) or the other terms of this Lease, including, but not limited to, work that is Landlord&#146;s responsibility under any warranty set forth herein, Tenant shall perform all repairs and maintenance required to
keep the Premises in a reasonably good and clean condition and in working order and otherwise in compliance with the Incentive Agreements (including, but not limited to, interior walls, windows, Mechanical Systems, interior lighting, parking lot
lights, parking areas, access drives, sidewalks, exterior utility lines and facilities, landscaping, storm water drainage, detention and/or retention facilities, and signage), excluding ordinary wear and tear, damage caused by fire, casualty or any
Taking, and utility lines and facilities to be maintained by any utility company. In addition, Tenant shall be responsible for (i)&nbsp;performing normal preventative maintenance to the roof of the Building substantially in accordance with the
applicable manufacturer&#146;s preventive maintenance requirements for said roof that are furnished to Tenant pursuant to Section&nbsp;9.03, and (ii)&nbsp;necessary maintenance and repairs to the roof membrane and related insulation above the roof
deck from and after the start of the second (2<SUP STYLE="font-size:85%; vertical-align:top">nd</SUP>) Extension Period assuming Tenant exercises the second Extension Option. All repairs and maintenance that are Tenant&#146;s responsibility under
this Lease shall be completed in a good and workmanlike manner and in compliance with all Applicable Laws. If any repairs, maintenance or replacements are required as a result of damage to the Premises caused by Landlord or its Affiliates, agents,
employees, contractors or representatives, excluding ordinary wear and tear and damage that is subject to the waiver set forth in Section&nbsp;11.04, then Landlord shall reimburse Tenant for the third party actual, verifiable and reasonable cost of
such repairs, maintenance or replacements, within sixty (60)&nbsp;days of Landlord&#146;s receipt of a written demand for the same from Tenant, accompanied by reliable evidence of the costs for which reimbursement is sought. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;Notwithstanding anything contained elsewhere in the Lease to the contrary, if (i)&nbsp;Tenant shall
replace any components of the Mechanical Systems (including, without limitation, any HVAC units serving the Premises) with Landlord&#146;s prior approval, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii)&nbsp;if
this Lease shall expire within three (3)&nbsp;years </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-21- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
after replacement of said components of the Mechanical Systems, then, upon expiration of this Lease, Landlord shall pay to Tenant a sum equal to the unamortized balance of the cost of the
replaced Mechanical Systems, which amortization shall be determined as of the date of such expiration, and such amortization shall be calculated on a ten (10)&nbsp;year straight line amortization commencing on the date of replacement. If Landlord
does not notify Tenant, in writing, of its objections to the replacement of any component of the Mechanical System (including, without limitation, any HVAC unit) within fifteen (15)&nbsp;days after Tenant requests such approval, in writing, then
Landlord shall be deemed to have approved such replacement. In the event of any dispute between Landlord and Tenant regarding the need for such replacements, Tenant shall retain an engineer or contractor reasonably acceptable to Landlord to review
the need for the same and such engineer&#146;s or contractor&#146;s determination shall be final and binding on the parties. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">9.03&nbsp;&nbsp;&nbsp;&nbsp;<U>Delivery of Warranties/Operating <FONT STYLE="white-space:nowrap">Manuals/As-Built</FONT>
Plans</U>. Within ninety (90)&nbsp;days after the Delivery Date, Landlord shall deliver to Tenant clean, readable copies of (i)&nbsp;all guarantees and warranties issued in connection with Landlord&#146;s Work, and (ii)&nbsp;all manufacturer&#146;s,
contractor&#146;s, subcontractor&#146;s and supplier&#146;s instructions and manuals related to Landlord&#146;s Work, and <FONT STYLE="white-space:nowrap">as-built</FONT> plans and specifications for Landlord&#146;s Work. Subject to the other terms
of this section, if Landlord fails to deliver all of the documents to Tenant required under this section within ninety (90)&nbsp;days after the Delivery Date and Landlord does not cure such failure within thirty (30)&nbsp;days after receiving
written notice from Tenant, then Tenant shall be entitled to receive a credit against the Rent equal to the product obtained by multiplying (i)&nbsp;the sum of Five Hundred and No/100 Dollars ($500.00) by (ii)&nbsp;the number of days during the
period commencing ninety (90)&nbsp;days after the Delivery Date and ending on the date Landlord has delivered all of such documents to Tenant. In the event Landlord disputes, in good faith, Tenant&#146;s assertion that Landlord has failed to provide
all of the documents required under this section, Landlord may give written notice to Tenant of such dispute prior to the end of the thirty (30)&nbsp;day cure period set forth above, which notice shall set forth (in detail) the entire basis upon
which Landlord disputes such assertion. Should Landlord timely dispute any assertion by Tenant that it has failed to provide all of the documents required under this section, in accordance with the preceding sentence, the parties shall endeavor, in
good faith to resolve such dispute, within thirty (30)&nbsp;days thereafter and Tenant shall not reduce the Rent pursuant to this section until such dispute is resolved in Tenant&#146;s favor, by agreement of the parties, court order or other means
agreed to by the parties (in writing). For purposes of this Section&nbsp;9.03, electronic delivery to Tenant&#146;s designated construction representative for the Project shall be sufficient so long as Landlord confirms the same has been successful.
</P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE X </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ALTERATIONS </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">10.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Alterations</U>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;After the Delivery Date, Tenant may, without Landlord&#146;s approval: (i)&nbsp;install all
equipment that Tenant deems necessary or desirable in connection with the Permitted Uses, whether now existing or hereafter developed, so long as the same do not exceed the load bearing capacity or otherwise materially and adversely damage the
structure of the Building, and Tenant complies with all Applicable Laws; and (ii)&nbsp;make any Alterations required to allow the use and operation of such equipment in the Premises in compliance with Applicable Laws; provided Tenant shall not alter
the roof, foundation or other structural elements of the Premises, unless Tenant obtains Landlord&#146;s prior written approval as provided below. In addition, without obtaining Landlord&#146;s approval, Tenant may make (i)&nbsp;changes to floor
coverings, wall coverings and paint of the interior of the Building, and (ii)&nbsp;interior, <FONT STYLE="white-space:nowrap">non-structural</FONT> Alterations to the Building in an amount that does not exceed the Alterations Threshold (defined
below) on a per item basis. The &#147;Alterations Threshold&#148; shall initially be One Hundred Thousand and No/100 Dollars ($100,000.00) and shall increase by fifteen percent (15%) on the fifth
(5<SUP STYLE="font-size:85%; vertical-align:top">th</SUP>) anniversary of the Rent </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-22- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
Commencement Date and every fifth (5<SUP STYLE="font-size:85%; vertical-align:top">th</SUP>) year thereafter. Except as otherwise expressly provided above, Tenant shall not make any Alterations
(including, but not limited to, any Alterations to the roof, foundation and structural elements of the Building) unless Landlord has approved such Alterations, in writing, which approval will not be unreasonably withheld, conditioned or delayed. If
Landlord does not notify Tenant, in writing, of its objections to any Alterations within thirty (30)&nbsp;days after Tenant requests that Landlord approve the same, in writing, then Tenant may deliver a subsequent notice to Landlord requesting
approval of such Alterations, and if Landlord fails to respond to such second (2<SUP STYLE="font-size:85%; vertical-align:top">nd</SUP>) notice within ten (10)&nbsp;days after receipt thereof, Landlord shall be deemed to have approved such
Alterations. Prior to commencing any Alterations, Tenant shall provide to Landlord proof of Tenant&#146;s insurance required under Section&nbsp;11.01(b) and shall cause all contractors performing such Alterations to furnish evidence of liability
insurance coverage with liability limits for personal injury, death and property damage of not less than One Million and No/100 Dollars ($1,000,000.00) per occurrence. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;All Alterations undertaken by Tenant: (i)&nbsp;must be completed by Tenant in a good and
workmanlike manner and in compliance with Applicable Laws; (ii)&nbsp;must be completed using new or <FONT STYLE="white-space:nowrap">like-new</FONT> materials of good quality; (iii)&nbsp;must not result in the load bearing capacity of the Building
or otherwise have a material adverse effect on the structural integrity of the Building; and (iv)&nbsp;must not increase the load on any of the Mechanical Systems beyond their published load limits or otherwise have a material adverse effect on the
Mechanical Systems. Tenant shall, at its expense, obtain all governmental permits and approvals required in connection with its Alterations. If Landlord&#146;s consent is required for any proposed Alterations under the other provisions of this
section, Tenant shall submit the construction plans and specifications for such Alterations to Landlord at the time Tenant requests Landlord&#146;s approval thereof and Tenant shall complete such Alterations substantially in accordance with the
plans and specifications approved (or deemed approved) by Landlord. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(c)&nbsp;&nbsp;&nbsp;&nbsp;Provided it complies with
the other terms of this Section&nbsp;10.01, Tenant shall have the right to install one (1)&nbsp;or more antennas, satellite dishes and other communications devices (collectively, &#147;Communication Facilities&#148;) on the roof of the Building. If
Tenant installs any Communications Facilities on the roof of the Building under the terms of this Lease or Landlord consents, in writing, to Tenant installing any other facilities on the roof of the Building or Tenant makes any Alterations to the
roof of the Building, Tenant shall: (i)&nbsp;not void or violate any roof warranty; (ii)&nbsp;follow the roof manufacturer&#146;s recommendations and requirements; (iii)&nbsp;use Landlord&#146;s roofing contractor or an approved roof manufacturer
contractor; and (iv)&nbsp;ensure the installation or alteration does not damage the roof or exceed the load bearing capacity of the roof. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(d)&nbsp;&nbsp;&nbsp;&nbsp;All of Tenant&#146;s Alterations forming a part of the Premises at the expiration or termination of
this Lease shall become the property of Landlord; provided, Tenant shall have the right to remove, at its option, all or any portion of its equipment, furnishing, fixtures, trade fixtures, equipment, machinery, racking, materials handling equipment
and other personal property, whether or not the same are physically fastened or attached to the Land or Improvements so long as Tenant repairs all material damage resulting from such removal. Tenant&#146;s repair obligation under the preceding
sentence shall survive the expiration or sooner termination of this Lease. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(e)&nbsp;&nbsp;&nbsp;&nbsp;Tenant shall have
the right to require that Landlord expand the Premises as provided in Section&nbsp;6 of <B><U>Exhibit&nbsp;B</U></B>. In addition, Tenant may, at its option, complete such expansion or any phase thereof, using its own funds, as provided on said
<B><U>Exhibit&nbsp;B</U></B>. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">10.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Liens</U>. Notice is hereby given that Landlord will not be
liable for any work, services, materials or labor furnished to Tenant during the Term, and no mechanic&#146;s, materialmen&#146;s or other lien arising or resulting from Tenant&#146;s failure to pay any amounts owed by Tenant (collectively,
&#147;Tenant Liens&#148;) shall attach to Landlord&#146;s interest in the Premises. In the event Tenant fails to release any Tenant </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-23- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
Liens encumbering the Premises (by posting a bond or other method) within thirty (30)&nbsp;days after Landlord notifies Tenant, in writing, of the filing thereof, Landlord may (but shall not be
obligated to) cause such Tenant Liens to be released and discharged, in which event Tenant shall reimburse Landlord for all third party actual, verifiable and reasonable costs that Landlord incurs in connection therewith, including, but not limited
to, reasonable attorneys&#146; fees within thirty (30)&nbsp;days of Tenant&#146;s receipt of an invoice from Landlord. In the event Landlord elects to release or discharge such Tenant Lien pursuant to this section the cost of paying off the Tenant
Lien shall not be considered unreasonable by Tenant for purposes of reimbursing Landlord. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XI </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>INSURANCE AND INDEMNITY </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">11.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Tenant&#146;s Insurance</U>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;Subject to the other terms hereof, throughout the Term, Tenant shall maintain, at its sole cost and
expense: (i)&nbsp;commercial liability insurance covering Tenant&#146;s activities and operations at the Premises, with a combined single limit for bodily or personal injury, including death, of not less than Three Million and No/100 Dollars
($3,000,000.00) per occurrence and an aggregate limit for such insurance of not less than Five Million and No/100 Dollars ($5,000,000.00); (ii) property insurance on the Improvements (including, without limitation, Tenant&#146;s Alterations) in an
amount equal to at least one hundred percent (100%) of the replacement cost of the buildings forming a part of the Improvements, excluding foundations, footings and paving, written on a &#147;Causes of Loss, Special Form&#148; basis or its
equivalent (the &#147;Premises Property Insurance&#148;); and (iii)&nbsp;property insurance (&#147;Tenant&#146;s Personal Property Insurance&#148;), written on a form not less broad than &#147;Causes of Loss&nbsp;&#150; Special Form&#148; basis or
its equivalent, covering Tenant&#146;s personal property at the Premises, in an amount equal to the full replacement value of such property. Tenant may satisfy the liability insurance requirements under this section, at Tenant&#146;s option, with
the combination of a base liability insurance policy and an umbrella liability insurance policy. The insurance policies that Tenant is required to obtain under this Lease shall be issued by a reputable insurance company licensed to do business in
the State of Missouri that have an A.M. Best Insurance Reports rating of at least <FONT STYLE="white-space:nowrap">A-</FONT> (or its equivalent), and Tenant&#146;s commercial liability insurance shall name Landlord, the County, and, upon
Landlord&#146;s written request, the Fee Mortgagee and Landlord&#146;s property manager, if any, as additional insureds with respect to claims arising from Tenant&#146;s negligence, but not in the event of injury or damage arising from
Landlord&#146;s or its lender&#146;s or property manager&#146;s acts or omissions. All insurance required under this section shall be consistently maintained without gaps in coverage. If Tenant fails to maintain any of the insurance required under
this Lease, then Landlord may (but shall have no obligation to) purchase such insurance, on behalf of Tenant, in which event Tenant shall reimburse Landlord for the reasonable cost of such insurance, upon demand. Within ten (10)&nbsp;days after
Landlord&#146;s written request, and in any event, at least thirty (30)&nbsp;days before the expiration of the current policy, Tenant shall provide Landlord with certificates of insurance evidencing the insurance that Tenant is required to maintain
hereunder and appropriate renewals. No failure by Tenant to maintain the insurance required hereunder shall relieve Tenant of any liability hereunder. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;From the commencement of construction of Tenant&#146;s Alterations until Tenant has completed such
Alterations, Tenant shall carry builder&#146;s risk insurance in an amount equal to one hundred percent (100%) of the replacement cost of Tenant&#146;s Alterations. Tenant shall furnish Landlord with policies or certificates evidencing such coverage
prior to commencing construction of Tenant&#146;s Alterations. Tenant shall cause all contractors performing such Alterations to furnish evidence of liability insurance coverage with liability limits for personal injury, death and property damage of
not less than One Million and No/100 Dollars ($1,000,000.00) per occurrence and naming Landlord, Landlord&#146;s lender, property manager, the County, and Tenant as Additional Insureds. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-24- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">11.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Landlord&#146;s Insurance</U>. Throughout the
Term, Landlord shall maintain, at its sole cost and expense: (i)&nbsp;commercial liability insurance covering Landlord&#146;s activities and operations at the Premises, with a combined single limit for bodily or personal injury, including death, of
Three Million and No/100 Dollars ($3,000,000.00) per occurrence and an aggregate limit for such insurance of Five Million and No/100 Dollars ($5,000,000.00); and (ii)&nbsp;any other insurance that Landlord is required to maintain under the Incentive
Agreements, including, but not limited to the Prime Lease, unless Tenant is maintaining the same pursuant to Section&nbsp;11.01. Landlord may satisfy the liability insurance requirements under this section, at its option, with the combination of a
base liability insurance policy and an umbrella liability insurance policy. The insurance policies that Landlord is required to obtain under this Lease shall be issued by a reputable insurance company licensed to do business in the State of Missouri
that have an A.M. Best Insurance Reports rating of at least <FONT STYLE="white-space:nowrap">A-</FONT> (or its equivalent), and Landlord&#146;s commercial liability insurance shall name Tenant and the County (throughout the term of the Prime Lease)
as additional insureds with respect to claims arising from Landlord&#146;s negligence, but not in the event of injury or damage arising from Tenant&#146;s acts or omissions. Subject to the other terms of this Lease, Tenant shall reimburse Landlord,
as additional rent, for the reasonable costs Landlord pays to maintain the insurance required under this Section&nbsp;11.02 (the &#147;Insurance Costs&#148;) during the Term; provided, the Insurance Costs shall be prorated for any partial calendar
year falling within the Term. Tenant shall pay <FONT STYLE="white-space:nowrap">one-twelfth</FONT> (1/12th) of Landlord&#146;s reasonable estimate of the Insurance Costs for each calendar year during the Term, on or before the first (1st) day of
each month during such calendar year. Landlord shall furnish Tenant with a written statement (an &#147;Insurance Statement&#148;) showing the final calculation of the amounts Tenant owes under this section for each calendar year during the Term
within sixty (60)&nbsp;days after the end of such calendar year. If the estimated payments made by Tenant pursuant to this section with respect to any calendar year are not sufficient to cover the Insurance Costs for such calendar year to be paid by
Tenant under this section, then Tenant shall pay Landlord the deficiency within sixty (60)&nbsp;days after Tenant&#146;s receipt of the Insurance Statement for such year. If the estimated payments made by Tenant pursuant to this section with respect
to any calendar year exceed the portion of the Insurance Costs for such calendar year to be paid by Tenant under this section, then the excess shall be credited against future amounts Tenant owes under this section; provided any such excess existing
at the expiration or termination of this Lease shall be promptly refunded to Tenant. In order to manage the Insurance Costs, Tenant shall have the right, annually, upon giving written notice to Landlord, to require that (i)&nbsp;Landlord obtain
quotes for such insurance from at least three (3)&nbsp;insurance companies that are reasonably acceptable to Tenant and Landlord, and (ii)&nbsp;Landlord shall purchase such insurance from the insurance company that submits the lowest quote. Without
limiting the generality of the foregoing, Tenant may require that Landlord obtain quotes for such insurance from Tenant&#146;s provider. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">11.03&nbsp;&nbsp;&nbsp;&nbsp;<U>Indemnities</U>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;Tenant agrees to indemnify, defend and hold harmless Landlord from all third party claims and
resulting lawsuits, actions, costs, expenses and liabilities arising from any personal injury or property damage occurring at the Premises that is caused by Tenant&#146;s use of the Premises during the Term, except to the extent the same is due to
the negligence or willful misconduct of Landlord or any of Landlord&#146;s Affiliates, employees, agents, contractors or representatives. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;Landlord agrees to indemnify, defend and hold harmless Tenant from all third party claims and
resulting lawsuits, actions, costs, expenses and liabilities arising or resulting from any negligence or willful misconduct of Landlord or any activities of Landlord or its Affiliates, employees, agents, contractors or representatives at the
Premises, except to the extent caused by the negligence or willful misconduct of Tenant or any of Tenant&#146;s Affiliates, employees, agents, contractors or representatives. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-25- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(c)&nbsp;&nbsp;&nbsp;&nbsp;Should any claim be asserted for which a right of
indemnity is claimed under this Section&nbsp;11.03, the indemnified party shall give written notice thereof to the indemnifying party. The indemnifying party shall thereafter have authority to defend, settle or otherwise deal with the suit or
proceeding as it deems fit; provided the indemnifying party shall not have the right to incur any obligation or liability on behalf of the indemnified party, make any admission or statement on behalf of the indemnified party, or bind the indemnified
party without the approval of the indemnified party which may be withheld in its sole and absolute discretion. The indemnifying party shall receive from the indemnified party all information in its custody or control necessary for the defense of
such suit or proceeding. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">11.04&nbsp;&nbsp;&nbsp;&nbsp;<U>Waiver of Claims/Subrogation Rights</U>. Notwithstanding
anything to the contrary contained herein, Landlord and Tenant each hereby waives all claims that it may have against the other party (and such other party&#146;s Affiliates, employees, agents, contractors and representatives) for losses and damages
that are actually covered by its insurance or that would have been covered had it maintained the insurance required under this Lease. If possible on commercially reasonable terms, Landlord and Tenant shall cause the insurers issuing their insurance
to waive all of their subrogation rights against the other party (and such other party&#146;s Affiliates, employees, agents, contractors and representatives), and each party shall supply the other with appropriate evidence confirming that such
waiver is in effect. For the purposes of this section, each party shall be deemed to be insured against losses and damages that are within the deductible of any of its insurance policies. The provisions of this section shall apply to claims
regardless of cause or origin, including, without limitation, claims arising due to negligence. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XII </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>FIRE&nbsp;&amp; CASUALTY </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">12.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Restoration</U>. Unless this Lease is terminated pursuant to Section&nbsp;12.02, if the
Premises are damaged by fire or other casualty, Tenant shall be responsible for performing all repairs and replacements (collectively, &#147;Casualty Restoration Work&#148;) required to fully restore the Premises (including, without limitation,
Tenant&#146;s Alterations) to the condition existing immediately prior to such fire or casualty in accordance with the terms hereof; provided, Tenant shall have the right to make Alterations to the Leased Premises to the extent required to comply
with Applicable Laws or as permitted under this Lease. Tenant shall diligently prosecute the Casualty Restoration Work to completion, in a good and workmanlike manner, using new or <FONT STYLE="white-space:nowrap">like-new</FONT> materials, and in a
manner that complies with Applicable Laws and is consistent with (or better than) the initial quality thereof. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">12.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Termination</U>. Tenant shall have the right to terminate this Lease if (i)&nbsp;the Premises
are damaged by fire or casualty and such damage cannot reasonably be repaired within two hundred and seventy (270)&nbsp;days after the date of such fire or casualty or (ii)&nbsp;the Casualty Restoration Work is not completed within ninety
(90)&nbsp;days after the end of the Restoration Period (hereinafter defined) applicable to any damage. Landlord or Tenant shall have the right to terminate this Lease if the Premises are damaged by fire or casualty, there are fewer than two
(2)&nbsp;years remaining in the Term and the cost of repairing such damage exceeds Two Million and No/100 Dollars ($2,000,000.00) or such damage renders all or substantially all of the Premises untenantable; provided, if Landlord elects to exercise
such termination right and Tenant thereafter exercises an Extension Option, then Landlord&#146;s exercise of such termination right shall be null and void, this Lease shall remain in full force and effect, and Tenant shall complete the Casualty
Restoration Work required as a result of such damage in accordance with the terms hereof. If Landlord and Tenant cannot agree upon the period required to restore any damage to the Premises caused by fire or casualty (the &#147;Restoration
Period&#148;) or the cost of repairing any such damage within thirty (30)&nbsp;days after the occurrence thereof, then Landlord shall engage an independent general contractor reasonably acceptable to Tenant, who has experience constructing or
reconstructing buildings similar to the Building, to determine the Restoration Period and the cost to repair such damage and such determination shall be binding upon the parties for purposes of this Section&nbsp;12.02. If Tenant or Landlord
</P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-26- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
desire to exercise the termination right under this Section&nbsp;12.02 following any damage to the Premises caused by fire or other casualty, then such terminating party shall so notify the other
party, in writing, within forty-five (45)&nbsp;days of the date of the fire or casualty, or the determination of the independent general contractor, as the case may be. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">12.03&nbsp;&nbsp;&nbsp;&nbsp;<U>Abatement</U>. The Rent shall not abate, in whole or in part, as a result of any damage to the
Leased Premises caused by fire or other casualty, except Tenant shall receive a credit against the rent equal to any insurance proceeds paid to Landlord for loss of rents on account of such damage. </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XIII </U></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>EMINENT
DOMAIN </U></P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">13.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Termination</U>. In the event of a taking of all of the Premises by
condemnation or eminent domain, this Lease shall automatically terminate, effective as of the date possession of the same is actually taken. If a material portion of the Premises is taken by condemnation or eminent domain and Tenant determines, in
its reasonable judgment, that such taking will have a material adverse effect on Tenant&#146;s ability to use the Premises, Tenant may terminate this Lease by giving written notice to Landlord within sixty (60)&nbsp;days after Tenant is notified of
such taking, in writing, by Landlord. Such termination shall be effective on the date of the taking. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">13.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Restoration</U>. In the event this Lease is not terminated after a taking of any portion of
the Premises, Landlord shall diligently perform the work (the &#147;Condemnation Restoration Work&#148;) required to restore the same as close as possible to the condition and functionality prior to such taking and Landlord shall be entitled to use
all condemnation awards paid on account of such taking of the Premises to pay the cost of such Condemnation Restoration Work, with any remaining funds being allocated to Landlord and Tenant in accordance with the terms of Section&nbsp;13.03;
provided (i)&nbsp;in no event shall Landlord be required to spend more than the amount of such condemnation awards to restore the Premises, and (ii)&nbsp;Tenant, not Landlord, shall be entitled to amounts paid on account of the taking of any of
Alterations paid for by Tenant that are not being restored by Landlord. In the event this Lease is not terminated as a result of any condemnation as provided in Section&nbsp;13.01 above, then the Rent shall be proportionately abated for the
remainder of the Term, based on the percentage reduction in the Gross Building Area resulting from such taking. In addition, the Rent shall be equitably abated while Landlord performs any Condemnation Restoration Work required under this section.
</P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">13.03&nbsp;&nbsp;&nbsp;&nbsp;<U>Awards</U>. Landlord shall be entitled to receive the entire award paid on account of a
taking of all or any portion of the Premises by condemnation, except Tenant shall be entitled to recover from the condemning authority all amounts awarded on account of Tenant&#146;s moving expenses, the positive value of Tenant&#146;s leasehold
estate in the Premises, and Tenant&#146;s Alterations to the Premises. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XIV </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ASSIGNMENT AND SUBLETTING </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">14.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Assignment&nbsp;&amp; Subletting</U>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;Tenant may do any or all of the following, from time to time, without obtaining Landlord&#146;s
consent: </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:13%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(i)&nbsp;&nbsp;&nbsp;&nbsp;assign this Lease or sublet all or a portion of the Premises to: (A)&nbsp;any
Affiliate of Tenant; (B)&nbsp;any Person resulting from a merger, consolidation, reorganization, acquisition or private placement involving Tenant or any of its Affiliates, including, without limitation, American Outdoor Brands Corporation and its
successors and assigns (&#147;AOB&#148;); (C) any Person purchasing all or a </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-27- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
majority of the assets of Tenant, AOB or any division of AOB; or (D)&nbsp;any Person in conjunction with a sale, redemption, hypothecation, conversion, exchange, transfer or similar disposition
of all or a majority of the stock of Tenant or AOB; </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:13%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(ii)&nbsp;&nbsp;&nbsp;&nbsp;sublet twenty-five percent (25%) or less
of the Premises to any Person; and </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:13%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(iii)&nbsp;&nbsp;&nbsp;&nbsp;grant a license or other right of occupancy to any of
Tenant&#146;s Affiliates or any contractor, subcontractor, vendor, supplier or consultant of Tenant or any of its Affiliates allowing it to utilize a portion of the Premises. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;Except as otherwise expressly provided in Section&nbsp;14.01(a), Tenant shall not assign the Lease
or sublet more than twenty-five percent (25%) of the Premises to any Person without obtaining Landlord&#146;s prior written approval, which approval shall not be unreasonably withheld, qualified or delayed. If Landlord does not notify Tenant, in
writing, of its specific objections to any proposed assignment of this Lease or subletting of all or a portion of the Premises within thirty (30)&nbsp;days after Tenant requests Landlord&#146;s approval of the same, in writing, then Landlord shall
be deemed to have approved such assignment or subletting. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(c)&nbsp;&nbsp;&nbsp;&nbsp;Tenant shall give Landlord written
notice of any assignment pursuant to this section that does not require Landlord&#146;s prior consent. Any assignee of Tenant&#146;s interest in this Lease shall execute and deliver an assignment and assumption agreement, in writing, whereby such
assignee assumes and agrees to perform and observe all of the covenants and agreements of Tenant under this Lease first arising and related to periods from and after the date of the assignment. Any sale, assignment, mortgage, or transfer of this
Lease or the Premises which is not in compliance with the provisions of this section shall be null and void and of no force and effect. The consent by Landlord to any assignment of this Lease by Tenant shall not be construed as relieving Tenant from
obtaining the express prior written consent of Landlord to any further assignment that requires Landlord&#146;s consent under this section. Except to the extent expressly provided on <B><U>Exhibit&nbsp;I</U></B>, in no event will any assignment of
this Lease or subletting of the Premises result in Tenant being released from any of its obligations or liabilities under this Lease. </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XV </U></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>LEASEHOLD
MORTGAGE </U></P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">15.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Leasehold Mortgages</U>. Tenant shall have the right to enter into
mortgages, deeds of trust, deeds to secure debt, security deeds, financing statements and other security agreements (collectively, &#147;Leasehold Mortgages&#148;) encumbering Tenant&#146;s interest in this Lease and the leasehold estate created
hereby (collectively, the &#147;Leasehold Estate&#148;), without obtaining Landlord&#146;s consent, but upon at least thirty (30)&nbsp;days&#146; prior written notice to Landlord, which notice (a &#147;Leasehold Mortgage Notice&#148;) shall contain
the name, address, contact person, telephone number and facsimile number of any Person to whom Tenant grants a Leasehold Mortgage (such a Person being referred to as a &#147;Leasehold Mortgagee&#148;). In the event Tenant enters into or grants any
Leasehold Mortgage, Landlord and Tenant agree that the provisions of <B><U>Exhibit&nbsp;J</U></B> shall apply to such Leasehold Mortgage and govern the obligations of the parties with respect thereto. Notwithstanding anything contained in this
Section&nbsp;15.01, Tenant&#146;s Leasehold Mortgages shall not encumber Landlord&#146;s interest in the Premises. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XVI </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>SECURITY FOR PERFORMANCE; DEFAULTS </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">16.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Security for Performance</U>. As security for performance of Tenant&#146;s obligations
hereunder, American Outdoor Brands Corporation has executed a guaranty of even date herewith. In </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-28- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
addition to any rights or remedies of Landlord for any Tenant Default, Landlord may pursue all remedies against said guarantor available under such guaranty. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">16.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Tenant Default</U>. Tenant shall be in default under this Lease only upon the occurrence of
one (1)&nbsp;or more of the following events (each a &#147;Tenant Default&#148;): </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(i)&nbsp;&nbsp;&nbsp;&nbsp;Tenant&#146;s failure to pay any Rent when due, unless such failure is cured by Tenant within ten
(10)&nbsp;days after it receives written notice from Landlord; or </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(ii)&nbsp;&nbsp;&nbsp;&nbsp;Tenant&#146;s failure to
comply with any of the terms of this Lease other than those related to the payment of Rent, unless such failure is cured within thirty (30)&nbsp;days after Tenant receives written notice from Landlord; provided if such failure cannot reasonably be
cured within the aforementioned thirty (30)&nbsp;day period, then no Tenant Default shall be deemed to have occurred so long as Tenant commences to cure such failure within thirty (30)&nbsp;days after receiving written notice from Landlord and
completes such cure within a reasonable time thereafter; or </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(iii)&nbsp;&nbsp;&nbsp;&nbsp;(A) the filing by or against
Tenant of a petition (voluntary or involuntary) seeking to have Tenant declared bankrupt or insolvent, unless the petition is dismissed within sixty (60)&nbsp;days after its filing, (B)&nbsp;the appointment of a receiver or trustee for all or
substantially all of Tenant&#146;s assets, or (C)&nbsp;the assignment of all or substantially all of Tenant&#146;s assets for the benefit of its creditors. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">16.03&nbsp;&nbsp;&nbsp;&nbsp;<U>Remedies</U>. Upon the occurrence of any Tenant Default, Landlord may pursue one (1)&nbsp;or
more of the following remedies: </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(i)&nbsp;&nbsp;&nbsp;&nbsp;Without terminating this Lease, enter upon and take possession
of the Premises, expel or remove Tenant, and relet the Premises and receive the rent therefor, with or without due process and Tenant hereby expressly waives any and all claims for damages resulting therefrom. In the event Landlord elects to
exercise the remedy provided under this subsection, Tenant agrees to reimburse Landlord for (A)&nbsp;any third party actual, verifiable and reasonable costs and expenses that Landlord incurs to effect compliance with Tenant&#146;s obligations under
this Lease through the date the Premises are relet, (B)&nbsp;the costs Landlord incurs to recover possession of the Premises from Tenant, including, but not limited to, reasonable attorneys&#146; fees, (C)&nbsp;the market brokerage commissions,
advertising costs and other similar expenses Landlord incurs to relet the Premises, and (D)&nbsp;an amount equal to the difference between the Monthly Rent and other sums that Tenant is required to pay hereunder during the remainder of the Term
(calculated without taking into account any unexercised Extension Option) and the rent received by Landlord on account of such reletting during said period (or if Landlord takes possession of the Premises for its own benefit, the fair rental value
thereof), which amount shall be paid monthly, in arrears. In the event Landlord is successful in reletting the Premises at a rental in excess of that agreed to be paid by Tenant pursuant to the terms of this Lease, Landlord shall be entitled to
retain such excess, provided any such excess that is allocable to periods falling within the Term shall be first applied to pay the costs Landlord incurs to relet the Premises (including, without limitation, costs and expenses that Landlord incurs
to effect compliance with Tenant&#146;s obligations under this Lease, the costs Landlord incurs to recover possession of the Premises, the brokerage commissions, advertising costs and other similar expenses Landlord incurs to relet the Premises, and
the cost of alterations to the Premises paid for by Landlord) and then to reduce any other amounts Tenant owes Landlord hereunder. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(ii)&nbsp;&nbsp;&nbsp;&nbsp;Terminate this Lease, in which event Tenant shall immediately surrender the Premises to Landlord,
and if Tenant fails to do so, Landlord may enter upon and take possession of the Premises and expel or remove Tenant. In the event this Lease is terminated pursuant to this subparagraph, Tenant agrees to reimburse Landlord for: (A)&nbsp;any unpaid
Rent that was due and owing prior to such termination, (B)&nbsp;any third party actual, verifiable and reasonable costs and expenses that </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-29- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
Landlord incurs to effect compliance with Tenant&#146;s obligations under this Lease through the date of such termination, (C)&nbsp;the third party actual, verifiable and reasonable costs
Landlord incurs to recover possession of the Premises from Tenant, including, but not limited to, reasonable attorneys&#146; fees, and (D)&nbsp;any other actual damages that Landlord reasonably incurs as a result of the termination of this Lease.
</P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(iii)&nbsp;&nbsp;&nbsp;&nbsp;Without terminating this Lease, enter upon the Premises, by force if necessary, without
being liable for prosecution or any claim for damages thereof, and do whatever Tenant is obligated to do under the terms of this Lease; and Tenant agrees to reimburse Landlord, on demand, for any third party actual, verifiable and reasonable
expenses which Landlord may incur in effecting compliance with Tenant&#146;s obligations under this Lease. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(iv)&nbsp;&nbsp;&nbsp;&nbsp;Pursue any other remedy available at law or in equity, subject to the limitations set forth in the
other provisions of this Lease. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">In the event Tenant fails to pay such amount and does not cure such failure within the
period provided in Section&nbsp;16.02, Landlord may exercise any other rights or remedies available at law or in equity and Landlord shall be entitled to recover from Tenant any additional costs associated with Landlord&#146;s recovery of such
reimbursements pursuant to Section&nbsp;26.17. In no event shall Tenant be liable for consequential, punitive or exemplary damages as a result of its default hereunder. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">Forbearance by Landlord to enforce one or more of the remedies herein provided upon a Tenant Default shall not be deemed or
construed to constitute a waiver of Landlord&#146;s right to enforce any such remedies with respect to any subsequent Tenant Default. Landlord shall use reasonable efforts to mitigate the damages arising out of or resulting from Tenant&#146;s
default under or breach of this Lease. All rights and remedies contained herein shall be deemed cumulative and not exclusive of one another. </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XVII </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>LANDLORD&#146;S DEFAULT </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">17.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Landlord Default</U>. The following shall constitute a default by Landlord under this Lease (a
&#147;Landlord Default&#148;): (i)&nbsp;Landlord&#146;s failure to complete Landlord&#146;s Work within thirty (30)&nbsp;days after the Outside Delivery Date in accordance with ARTICLE&nbsp;III, <B><U>Exhibit B</U></B>, and the other terms hereof;
(ii)&nbsp;Landlord&#146;s suspension or abandonment of construction of Landlord&#146;s Work for a period of more than thirty (30)&nbsp;consecutive business days after the Commencement Deadline (as defined in <B><U>Exhibit&nbsp;B</U></B>); (iii)
Landlord&#146;s failure to pay any uncontested amount that it owes Tenant under this Lease, unless such default is cured within ten (10)&nbsp;days after Tenant notifies Landlord of such failure, in writing; or (iv)&nbsp;any other default under or
breach of this Lease by Landlord, unless Landlord cures such default or breach within thirty (30)&nbsp;days after Tenant gives written notice to Landlord thereof, in writing; provided, if any default or breach by Landlord other than those described
in (i), (ii) or (iii)&nbsp;of this section cannot reasonably be cured within thirty (30)&nbsp;days and Landlord commences to cure the same within thirty (30)&nbsp;days after receiving written notice from Tenant, then no Landlord Default shall be
deemed to have occurred so long as Landlord is diligently and continuously curing such default or breach. In the event of any Landlord Default, Tenant shall have the right (but not the obligation) to attempt to cure such Landlord Default on behalf
of Landlord, in addition to its other rights and remedies under this Lease and at law or in equity, subject to the limitations expressly set forth in the other provisions of this Lease; provided Tenant shall not complete the initial construction of
Landlord&#146;s Work pursuant to this section. Notwithstanding the foregoing, in cases of emergency or where Landlord&#146;s default under or breach of this Lease threatens to result in damage to any portion of the Premises or Tenant&#146;s property
therein or threatens to cause a material interference with Tenant&#146;s business operations in the Premises, then Tenant shall have the right (but not the obligation) to immediately cure such default or breach, without the necessity of giving
Landlord advance notice or affording it an opportunity to cure the same. In the event </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-30- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
Tenant endeavors to cure any default or breach by Landlord pursuant to this section (including, but not limited to, any Landlord Default), Landlord shall reimburse Tenant for the third party
actual, verifiable and reasonable costs Tenant incurs in connection therewith. Landlord shall pay any amounts that it owes Tenant under this Section&nbsp;17.01 within thirty (30)&nbsp;days after Tenant&#146;s written demand for the same. If Landlord
fails to pay any amount that Landlord owes Tenant under this section or the other provisions of this Lease within thirty (30)&nbsp;days after receiving Tenant&#146;s written demand for the same, Tenant may deduct such amount from the Rent due under
this Lease so long as the same does not to exceed fifty percent (50%) of the Monthly Rent otherwise due hereunder. If Landlord disputes, in good faith, Tenant&#146;s right to deduct any amount from the Monthly Rent pursuant to the preceding sentence
and Landlord notifies Tenant of such dispute, in writing, within thirty (30)&nbsp;days after Tenant deducts such amount from the Monthly Rent, then Tenant shall deposit such amount, in escrow, until the dispute is resolved by written agreement of
the parties, court order or other means agreed to by the parties (in writing). Tenant shall also have all other remedies available at law or in equity on account of any Landlord Default, including, without limitation, the right to terminate this
Lease, and nothing in this section shall be deemed to limit any of Tenant&#146;s remedies set forth in <B><U>Exhibit&nbsp;B</U></B> or any of the other provisions hereof; provided, Tenant may only terminate this Lease on account of Landlord&#146;s
failure to complete Landlord&#146;s Work and/or deliver possession of the Premises to Tenant in accordance with <U><B>Exhibit&nbsp;B</B></U>. </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XVIII </U></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>QUIET
ENJOYMENT </U></P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">18.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Quiet Enjoyment</U>. Subject to the terms of this Lease and the Prime
Lease, Landlord covenants that Tenant shall peacefully and quietly have, hold and enjoy the Premises throughout the Term, without any hindrance, molestation or ejection whatsoever. </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XIX </U></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>RIGHT OF
ENTRY </U></P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">19.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Right of Entry</U>. Landlord shall have the right to enter the Premises to:
(i)&nbsp;conduct inspections; (ii)&nbsp;perform maintenance, repairs and replacements that are its responsibility under this Lease; (iii)&nbsp;show the Premises to prospective purchasers of the Premises and lenders; and (iv)&nbsp;show the Premises
to prospective tenants during the last twelve (12)&nbsp;months of the Term; provided Landlord shall use commercially reasonable efforts to avoid interference with the use and enjoyment of the Premises. Except in cases of emergency, Landlord shall
give Tenant at least forty-eight (48)&nbsp;hours advanced notice before entering upon the Premises and Landlord shall use reasonable efforts to schedule such entry at a time that is reasonably acceptable to Tenant. In the event emergency conditions
exist which materially threaten the Premises and Tenant is not diligently addressing the same, Landlord may immediately enter the Premises to prevent or mitigate the emergency conditions or damage or injury to persons or property, and no such entry
shall require prior notice to Tenant or constitute an eviction hereunder; provided, Landlord shall use reasonable efforts to immediately notify Tenant of such condition and not to interfere with Tenant&#146;s operations or damage Tenant&#146;s
property. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XX </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>SURRENDER </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">20.01&nbsp;&nbsp;&nbsp;&nbsp;Surrender. Upon the expiration or earlier termination of this Lease: (i)&nbsp;Tenant shall quit
and surrender possession of the Premises to Landlord in broom clean condition, free of Tenant&#146;s personal property, furniture, moveable trade fixtures and equipment, and (ii)&nbsp;provide Landlord with the keys or combinations for all locks in
the Premises. Tenant shall promptly repair all material damage to the Premises resulting from the removal of Tenant&#146;s furnishings, trade fixtures and other personal property. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-31- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XXI </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>SUBORDINATION, <FONT STYLE="white-space:nowrap">NON-DISTURBANCE</FONT> AND ATTORNMENT </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">21.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Subordination</U>. This Lease shall be subject and subordinate to the lien of any mortgage,
deed of trust, deed to secure debt, security deed, financing statement or other security interests now or hereafter encumbering Landlord&#146;s interest in the Premises (individually, a &#147;Fee Mortgage&#148; and collectively the &#147;Fee
Mortgages&#148;), including, but not limited to, all renewals, modifications, consolidations, replacements, amendments, supplements and extensions thereof; provided, as a condition to such subordination, the holder of the Fee Mortgage (the &#147;Fee
Mortgagee&#148;) must agree, in writing, not to disturb Tenant&#146;s possession of the Premises and the rights and privileges granted to Tenant under this Lease so long as there is no outstanding Tenant Default, by executing a subordination, <FONT
STYLE="white-space:nowrap">non-disturbance</FONT> and attornment agreement in the form attached hereto as <B><U>Exhibit&nbsp;K</U></B> or another form reasonably acceptable to Tenant (an &#147;SNDA&#148;). Notwithstanding anything herein to the
contrary, if any Fee Mortgagee elects to have Tenant&#146;s interest in this Lease superior to its Fee Mortgage, then by notice to Tenant from such Fee Mortgagee, this Lease shall be deemed superior to such Fee Mortgage, whether this Lease was
executed before or after the same. Landlord represents and warrants to Tenant as of the Effective Date that Landlord has not granted or entered into any mortgages, deeds of trust, deeds to secure debt, security deeds, financing statements, security
agreements or other liens encumbering the Premises. Landlord shall furnish Tenant with an SNDA from Landlord&#146;s construction lender at the time it closes the Construction Loan. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">21.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Attornment</U>. If Landlord&#146;s interest in the Premises is transferred to or acquired by a
Fee Mortgagee or any purchaser at a foreclosure sale (a &#147;Foreclosure Purchaser&#148;), (i) Tenant shall be bound to such Fee Mortgagee or Foreclosure Purchaser under the terms of this Lease, (ii)&nbsp;Tenant shall thereafter attorn to such Fee
Mortgagee or Foreclosure Purchaser, as the landlord hereunder, after it is notified of such transfer, unless this Lease is terminated in accordance with the provisions contained in this Lease, and (iii)&nbsp;such Fee Mortgagee or Foreclosure
Purchaser shall be bound by all of the terms of this Lease that are applicable to Landlord and shall, subject to the other terms of this section, satisfy all of Landlord&#146;s obligations and liabilities hereunder. The foregoing provision shall be
self-operative; provided, however, Tenant shall, upon written demand, execute documentation confirming the matters set forth in this section. Any Fee Mortgagee or Foreclosure Purchaser succeeding to the interest of Landlord in the Premises shall not
be (i)&nbsp;bound by any payment of Rent made by Tenant more than one (1)&nbsp;month in advance,<B><I> </I></B>(ii)&nbsp;liable due to any act or omission of a prior landlord (including, without limitation, Landlord), provided to the extent any
default by Landlord under this Lease is continuing, such Fee Mortgagee or Foreclosure Purchaser, as applicable, shall be responsible for curing the same after it acquires Landlord&#146;s interest in the Premises, (iii)&nbsp;subject to any offsets or
defenses of Tenant arising or related to periods prior to the date the Fee Mortgagee or Foreclosure Purchaser acquires such interest, or (iv)&nbsp;responsible for any security or other deposit not transferred to it or (v)&nbsp;bound by any amendment
of this Lease that is not approved by it, in writing, or is not in writing and signed both by Tenant and Landlord. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XXII
</U></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>NOTICES </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">All notices, consents, approvals and other communications (collectively, &#147;Notices&#148;) that may be or are required to
be given by either Landlord or Tenant under this Lease shall be properly made only if in writing and sent to the address of Landlord or Tenant, as applicable, set forth below, as the same is modified in accordance herewith, by hand delivery, U.S.
Certified Mail (Return Receipt Requested) or nationally recognized overnight delivery service. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-32- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">


<TABLE CELLSPACING="0" CELLPADDING="0" WIDTH="84%" BORDER="0" STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:10pt" ALIGN="center">


<TR>
<TD WIDTH="13%"></TD>
<TD VALIGN="bottom" WIDTH="3%"></TD>
<TD WIDTH="84%"></TD></TR>


<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">If&nbsp;to&nbsp;Landlord:</P></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Ryan Boone County, LLC</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">c/o Ryan Companies US, Inc.</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">533 South Third Street, Suite 100</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Minneapolis, MN 55415</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Attn: Casey Hankinson</P></TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="8"></TD>
<TD HEIGHT="8" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">with&nbsp;a&nbsp;copy&nbsp;to:</P></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Ryan Companies US, Inc.</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">533 South Third Street, Suite 100</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Minneapolis, MN 55415</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Attn: Audra Williams</P></TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="8"></TD>
<TD HEIGHT="8" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">If to Tenant:</P></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Smith&nbsp;&amp; Wesson Corp.</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">2100 Roosevelt Avenue</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Springfield, MA 01104</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Attn: Robert J. Cicero</P></TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="8"></TD>
<TD HEIGHT="8" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">with Copy to:</P></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Smith&nbsp;&amp; Wesson Corp.</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">2100 Roosevelt Avenue</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Springfield, MA 01104</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Attn: Lewis Hornsby</P></TD></TR>
</TABLE> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">Either party may change its address for Notices by giving a ten (10)&nbsp;day prior written
notice to the other party in accordance with this provision. Notices shall be deemed received on the date of actual delivery; provided if either Landlord or Tenant refuses to accept the delivery of any Notice, such notice shall be deemed to have
been actually delivered on the date of such refusal. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XXIII </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>REPRESENTATIONS AND WARRANTIES </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">23.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Landlord&#146;s Representations</U>. Landlord hereby represents and warrants to Tenant, as of
the Effective Date, that: (i)&nbsp;Landlord is a limited liability company duly organized, validly existing and in good standing under the laws of the State of Minnesota; (ii)&nbsp;Landlord has all power and authority necessary for Landlord to
execute and deliver this Lease and perform all of Landlord&#146;s obligations under this Lease; (iii)&nbsp;the person executing this Lease on behalf of Landlord is duly authorized by Landlord to bind Landlord; (iv)&nbsp;the execution, delivery and
performance of this Lease by Landlord does not conflict with or result in a violation of any judgment, order or decree of any court or arbiter or any contract, agreement or other instrument; (v)&nbsp;Landlord has not filed or threatened to file any
voluntary petition in bankruptcy or sought to reorganize its affairs under the Bankruptcy Code of the United States or any other federal, state or local law related to bankruptcy, insolvency or relief for debtors, Landlord has not been adjudicated
as bankrupt or insolvent, and Landlord has not had an involuntary petition filed against it under the Bankruptcy Code of the United States or any other federal, state or local law related to bankruptcy, insolvency or relief for debtors;
(vi)&nbsp;there are no lawsuits, arbitration proceedings or other similar actions pending or, to Landlord&#146;s actual knowledge, threatened against Landlord that would have a material adverse effect on Landlord&#146;s ability to satisfy its
obligations under this Lease or with respect to the Premises; (vii)&nbsp;Landlord is the owner of good and marketable fee simple absolute title to the Land, free and clear of all easements, liens, claims, encumbrances and other exceptions to title,
except for the Permitted Exceptions; (viii)&nbsp;there are no pending or, to Landlord&#146;s actual knowledge, threatened governmental actions, investigations or proceedings that affect or will affect the Premises (including, but not limited to,
condemnation or eminent domain proceedings, plans to modify an abutting road or proposed assessments); (ix) upon completion of the Landlord&#146;s Work, water, sewer, electricity, gas and telephone service will be provided to the Premises, in the
capacities set forth in and in accordance with the Final Plans and Specifications, through lines and facilities located in adjoining public streets, or if </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-33- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
they pass through adjoining private land, do so in accordance and compliance with valid, perpetual easements and will be connected to the public utility systems serving the areas where the
Premises are located; (x)&nbsp;to Landlord&#146;s actual knowledge, no Hazardous Substances have been discharged, disbursed, released, stored, treated, generated, disposed of, incorporated into or allowed to escape on, under or about the Premises,
except for Hazardous Substances described in Section&nbsp;7.03(b) or any reports expressly described therein; (xi)<B><I></I></B>&nbsp;Landlord and its Affiliates are not and will not become a person or entity with whom U.S. persons are prohibited
from doing business under Legal Requirements, including, without limitation, the regulations of the Office of Foreign Asset Control (&#147;<U>OFAC</U>&#148;) of the Department of Treasury (e.g. OFAC&#146;s Specially Designated and Blocked Persons
list), Executive Order 13224, and the USA Patriot Act; and (xii)&nbsp;Landlord is not aware of any fact, event or circumstance that could have a material adverse effect on the Land, Landlord&#146;s Work or the Premises, excluding general market
conditions. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">23.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Tenant&#146;s Representations</U>. Tenant hereby represents and warrants to
Landlord, as of the Effective Date, that: (i)&nbsp;Tenant is corporation duly organized, validly existing and in good standing under the laws of the State of Delaware; (ii)&nbsp;Tenant has all power and authority necessary for Tenant to execute and
deliver this Lease and perform all of Tenant&#146;s obligations under this Lease; (iii)&nbsp;the person executing this Lease on behalf of Tenant is duly authorized by Tenant to bind Tenant; (iv)&nbsp;the execution, delivery and performance of this
Lease by Tenant does not conflict with or result in a violation of any judgment, order or decree of any court or arbiter or any contract, agreement or other instrument; (v)&nbsp;Tenant has not filed or threatened to file any voluntary petition in
bankruptcy or sought to reorganize its affairs under the Bankruptcy Code of the United States or any other federal, state or local law related to bankruptcy, insolvency or relief for debtors, Tenant has not been adjudicated as bankrupt or insolvent,
or Tenant has not had an involuntary petition filed against it under the Bankruptcy Code of the United States or any other federal, state or local law related to bankruptcy, insolvency or relief for debtors; (vi)&nbsp;there are no lawsuits,
arbitration proceedings or other similar actions pending or, to Tenant&#146;s actual knowledge, threatened against Tenant that would have a material adverse effect on Tenant&#146;s ability to satisfying its obligations under this Lease in the event
a judgment is entered against Tenant; and (vii)&nbsp;Tenant and its Affiliates are not and will not become a person or entity with whom U.S. persons are prohibited from doing business under Legal Requirements, including, without limitation, the
regulations of the Office of Foreign Asset Control (&#147;<U>OFAC</U>&#148;) of the Department of Treasury (e.g. OFAC&#146;s Specially Designated and Blocked Persons list), Executive Order&nbsp;13224, and the USA Patriot Act. </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XXIV </U></P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>PURCHASE
OPTION </U></P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">24.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Grant of Option</U>. Tenant shall have the right and option to purchase the
Premises from Landlord (the &#147;Purchase Option&#148;) upon and in accordance with the provisions of this ARTICLE&nbsp;XXIV. In the event Tenant desires to exercise the Purchase Option, Tenant may do so by giving written notice to Landlord (a
&#147;Purchase Option Notice&#148;) within one hundred twenty (120)&nbsp;days after Landlord commences construction of the Building and notifies Tenant of such fact, in writing. The Purchase Option, once exercised, shall be a binding contract for
the purchase and sale of the Premises on and subject to the terms and conditions set forth herein. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">24.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Purchase Price</U>. Subject to the prorations and adjustments set forth herein, in the event
Tenant elects to exercise the Purchase Option, the purchase price (the &#147;Purchase Price&#148;) for the Premises shall be equal to one hundred six percent (106%) of the lesser of (i)&nbsp;the Project Costs actually incurred, paid and documented
by Landlord, or (ii)&nbsp;the Guaranteed Maximum Project Costs. At the closing and consummation of the purchase and sale of the Premises (the &#147;Closing&#148;), Tenant shall pay the Purchase Price to Landlord, in immediately available funds. </P>

 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-34- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">24.03&nbsp;&nbsp;&nbsp;&nbsp;<U>Title Insurance</U>. Tenant&#146;s obligations to
purchase the Premises is conditioned on Tenant receiving an owner&#146;s title policy in the amount of the Purchase Price (the &#147;Owner&#146;s Title Policy&#148;). The Title Policy shall: (i)&nbsp;be based on a title examination of the Property
conducted by Tenant&#146;s counsel or a national title insurance company selected by Tenant (the &#147;Title Company&#148;), and (ii)&nbsp;insure good and marketable fee simple title to the Premises in Tenant, subject only to the Permitted
Exceptions. In the event Tenant is unable to obtain the Owner&#146;s Title Policy or the same does not satisfy the requirements of this Section&nbsp;24.02, Tenant may, as its sole and exclusive remedy, terminate and cancel its exercise of the
Purchase Option within ten (10)&nbsp;days after Tenant&#146;s receipt of a title commitment to issue Owner&#146;s Title Policy, in which event this Lease shall remain in full force until the expiration or earlier termination of the Term, as if the
Purchase Option had never been exercised, but the Purchase Option shall no longer be of any force or effect. If Tenant fails to terminate the exercise of the Purchase Option as provided herein, Tenant&#146;s right to terminate the exercise of the
Purchase Option shall be deemed waived. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">24.04&nbsp;&nbsp;&nbsp;&nbsp;<U>Closing</U>. The Closing shall take place on the
date that is fifteen (15)&nbsp;days after the Delivery Date or on such other date as is agreed upon by Landlord and Tenant, in writing. The Closing shall be conducted at the office of the Title Company that is issuing the Owner&#146;s Title Policy.
At the Closing, Landlord shall deliver the following items to Tenant, properly executed and notarized: (i)&nbsp;a special warranty deed, in form and content reasonably acceptable to Landlord and Tenant (the &#147;Deed&#148;), conveying good and
marketable fee simple title to the Premises to Tenant, free of all Monetary Liens (including, without limitation, Fee Mortgages) and subject only to the Permitted Exceptions; (ii)&nbsp;an instrument assigning the Landlord&#146;s right, title and
interest in the Incentive Agreements to Tenant, including, but not limited to, the Prime Lease; (iii)&nbsp;an owner&#146;s affidavit, in form and content sufficient to have the mechanics&#146; and materialmen&#146;s exception, rights of parties in
possession exception and any other standard exceptions removed from the Owner&#146;s Title Policy and the gap insured; (iv)&nbsp;evidence, reasonably satisfactory to Tenant and its title insurance company, that Landlord is duly authorized and
empowered to convey the Excess Land to Tenant and perform its other obligations hereunder, including, but not limited to, formation documents, resolutions and certificates of good standing; and (v)&nbsp;all other documents, instruments, certificates
and affidavits that are reasonably necessary to consummate the transaction contemplated by this ARTICLE&nbsp;XXIV, including, without limitation, a settlement sheet and an IRS&nbsp;&#167;1445 certificate. At or prior to Closing, Landlord shall cause
all Monetary Liens (including, without limitation, Fee Mortgages) affecting the Premises to be released and discharged, except for any liens resulting directly from Tenant&#146;s affirmative acts. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">24.05&nbsp;&nbsp;&nbsp;&nbsp;<U>Closing Costs and Prorations</U>. At Closing, Tenant shall pay the cost of recording the Deed,
all transfer taxes assessed as a result of the conveyance of the Premises to Tenant, the premiums for the Owner&#146;s Title Policy and Tenant&#146;s legal fees, and Landlord shall pay for Landlord&#146;s legal fees. Other costs and expenses of
Closing shall be paid by the parties in accordance with real estate customs in the area in which the Premises are located. Landlord and Tenant acknowledge that Tenant is required to pay the Property Taxes levied or assessed against the Premises
during the Term. Accordingly, such Property Taxes will not be prorated between the parties at Closing. Landlord shall pay, at Closing, all Property Taxes levied or assessed against the Premises that are allocable to periods outside the Term;
provided, if such Property Taxes are not payable at Closing, then Tenant shall receive a credit against the Purchase Price equal to the amount of such Property Taxes and Tenant shall responsible for paying such Property Taxes, prior to delinquency.
In the event the amount of such credit is not sufficient to pay the entire amount of the Property Taxes owed by Landlord under this section, Landlord shall reimburse Tenant, upon demand, for the difference between the amount of such Property Taxes
and the amount of such credit, which obligation shall survive the Closing and the termination of this Lease. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-35- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XXV </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>OWNERSHIP AND TRANSFER OF LANDLORD&#146;S INTEREST </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">25.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Ownership and Transfer Landlord&#146;s Interest</U>. Landlord shall not assign this Lease or
sell, transfer or convey its interest in the Premises to any Person prior to the Delivery Date, enter into any agreement prior to the Delivery Date pursuant to which Landlord is obligated to sell, transfer or convey its interest in the Premises to
any Person, or delegate any of its obligations or duties under this Lease prior to the Delivery Date, except to an Affiliate of Landlord that is approved, in writing, by Tenant and that assumes all of Landlord&#146;s obligations hereunder. Following
the Delivery Date, Landlord shall have the right to sell, assign or transfer its interest in this Lease and the Premises, without obtaining Tenant&#146;s consent, in compliance with the terms of this ARTICLE&nbsp;XXV and the other terms of this
Lease; provided, Landlord shall not assign this Lease or sell, transfer or convey its interest in the Premises in violation of the terms of <B><U>Exhibit&nbsp;L</U></B>. In no event shall the Premises or any interest therein or in Landlord be owned,
directly or in indirectly, by any Person in violation of <B><U>Exhibit&nbsp;L</U></B>. In addition, Landlord shall comply with the provisions of Section&nbsp;3 of <B><U>Exhibit&nbsp;L</U></B> in connection with the initial sale of the Property. In
the event of any sale, transfer or conveyance of Landlord&#146;s interest in the Premises, the transferor shall be automatically relieved of any and all obligations and liabilities on the part of Landlord accruing from and after the date of such
transfer; provided (i)&nbsp;the transferee assumes, in writing for the benefit of Tenant, such obligations and liabilities, and (ii)&nbsp;the transferor shall not be released from any obligations or liabilities arising from an event, matter or
circumstance occurring prior to such transfer. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>ARTICLE XXVI </U></P>
<P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center"><U>MISCELLANEOUS PROVISIONS </U></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.01&nbsp;&nbsp;&nbsp;&nbsp;<U>Consents</U>. Unless otherwise expressly stated herein, whenever Landlord&#146;s or
Tenant&#146;s consent is required under this Lease, such consent shall not be unreasonably withheld, qualified or delayed. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.02&nbsp;&nbsp;&nbsp;&nbsp;<U>Cooperation</U>. Upon Tenant&#146;s request, Landlord agrees, at no cost to Landlord, to
cooperate with, assist and join in Tenant&#146;s efforts to obtain any governmental permit, license or approval that Tenant deems necessary or desirable for Tenant&#146;s use and enjoyment of the Premises for any of the Permitted Uses or any other
uses approved by Landlord or any Alterations undertaken by or on behalf of Tenant in accordance with Section&nbsp;10.01. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.03&nbsp;&nbsp;&nbsp;&nbsp;<U>Estoppel Certificates</U>. Within ten (10)&nbsp;Business Days after its receipt of a written
request from the other party, Landlord or Tenant, as applicable, shall execute and deliver to the other party or its designee a written statement certifying to the extent true (i)&nbsp;that this Lease is unmodified and in full force and effect (or
if there have been modifications, that this Lease as modified is in full force and effect and identifying the modifications), (ii) that, to its actual knowledge, neither Landlord nor Tenant is in default under this Lease and no circumstance exists
which with the giving of notice, the passage of time, or both, would constitute such a default (or, if either party is in default or a circumstance exists which with the giving notice, the passage of time, or both, would constitute such a default,
then the nature of such default or circumstance shall be set forth in detail), (iii) that there are no actions, whether voluntary or otherwise, pending against it under the bankruptcy laws of the United States or any state thereof, and (iv)&nbsp;any
other facts related to the status of this Lease or the condition of the Premises, but only to the extent of the certifying party&#146;s actual knowledge thereof. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.04&nbsp;&nbsp;&nbsp;&nbsp;<U>Force Majeure</U>. In the event Landlord or Tenant is delayed in performing any of its
obligations under this Lease due to an Event of Force Majeure, then the period of time that Landlord or Tenant, as applicable, has to perform the obligation shall be extended by the period of such delay; provided, however, the provisions of this
section shall not operate to (i)&nbsp;excuse, extend or abate Tenant&#146;s </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-36- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
obligation to pay any Rent, or (ii)&nbsp;excuse Landlord&#146;s or Tenant&#146;s inability to perform its obligations hereunder because of inadequate finances, or (iii)&nbsp;extend the MHE Access
Deadline, the IT Room Delivery Date, or the Delivery Deadline (it being agreed extensions of the same are governed by Section&nbsp;3.01 of this Lease and Section&nbsp;4 of <B><U>Exhibit&nbsp;B</U></B>). </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.05&nbsp;&nbsp;&nbsp;&nbsp;<U>Landlord&#146;s Liens</U>. Landlord hereby waives any and all liens, whether statutory,
constitutional, possessory or otherwise, that Landlord may, now or hereafter, have with respect to any of Tenant&#146;s property, including, but not limited to, trade fixtures, furnishings, accounts receivable and equipment. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.06&nbsp;&nbsp;&nbsp;&nbsp;<U>Holdover</U>. Tenant shall have the right, at its option, to remain in possession of the
Premises for a period (the &#147;Permitted Holdover Period&#148;) of up to ninety (90)&nbsp;days following the expiration or termination of this Lease. During any portion of the Permitted Holdover Period that Tenant elects to remain in possession of
the Premises, Tenant shall continue to pay Monthly Rent, in the amount due immediately prior to the expiration or termination of this Lease, and the other terms of this Lease shall continue to apply; provided the Rent shall be prorated for any
partial month during the portion of the Permitted Holdover Period that Tenant elects to remain in possession of the Premises. Following the end of the Permitted Holdover Period, if Tenant remains in possession of the Premises, such holdover shall
result in the creation of a <FONT STYLE="white-space:nowrap"><FONT STYLE="white-space:nowrap">month-to-month</FONT></FONT> tenancy on the terms and conditions set forth in this Lease terminable by Landlord or Tenant, except the Monthly Rent during
such <FONT STYLE="white-space:nowrap"><FONT STYLE="white-space:nowrap">month-to-month</FONT></FONT> tenancy shall be one hundred fifty percent (150%) of the Monthly Rent that was payable immediately prior to the expiration of the Term. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.07&nbsp;&nbsp;&nbsp;&nbsp;<U>Financial Certificates</U>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;If the stock of Tenant or Tenant&#146;s parent company is not traded on a national United States
stock exchange, then Tenant shall, upon written request from Landlord (but not more frequently than once during any calendar year) submit to Landlord either a certified copy of Tenant&#146;s most recently prepared financial statements, prepared in
accordance with U.S. generally accepted accounting principles, or a certified statement setting forth Tenant&#146;s Net Worth signed by an officer of Tenant. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;Landlord shall keep all financial statements, certificates and information of Tenant confidential
and, except as may be required by law, shall not disclose the same without Tenant&#146;s consent; provided, Landlord may disclose the same to Landlord&#146;s lender and prospective lenders and prospective purchasers of the Premises who enter into a <FONT
STYLE="white-space:nowrap">non-disclosure</FONT> agreement, in a form reasonably acceptable to Tenant, that prohibits the disclosure thereof. The provisions of this Section&nbsp;26.07(b) shall survive the termination of this Lease. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.08&nbsp;&nbsp;&nbsp;&nbsp;<U>Brokers and Consultants</U>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;Except for Avison Young (&#147;Tenant&#146;s Broker&#148;), Tenant and Landlord each
(i)&nbsp;represents and warrants to the other that it has not dealt with any real estate broker, finder or listing agent in connection with this Lease, and (ii)&nbsp;agrees to indemnify, defend and hold harmless the other from and against any claim
for a commission, fee or other compensation made by a broker, finder or listing agent with whom it has dealt (or allegedly dealt). Landlord agrees to pay a commission to Tenant&#146;s Broker in an in connection with this Lease, when due, pursuant to
a separate written agreement; provided, such fee shall not exceed the amount expressly set forth in the budget attached as <B><U><FONT STYLE="white-space:nowrap">Exhibit&nbsp;B-3</FONT></U></B>. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;Upon the earlier to occur of December&nbsp;15, 2017 or the date on which Landlord closes the
Construction Loan, Landlord shall reimburse Tenant for the fees that Tenant paid to Bradley </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-37- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
Arant Boult Cummings LLP for its work related to Incentives and site selection, in the amount expressly set forth in the budget attached as
<B><U><FONT STYLE="white-space:nowrap">Exhibit&nbsp;B-3</FONT></U></B>. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(c)&nbsp;&nbsp;&nbsp;&nbsp;The provisions of this
section shall survive the expiration or termination of this Lease. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.09&nbsp;&nbsp;&nbsp;&nbsp;<U>Covenants Running With
Land</U>. The terms of this Lease shall run with the land and be binding on Landlord, Tenant and their respective successors and assigns. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.10&nbsp;&nbsp;&nbsp;&nbsp;<U>Successors and Assigns</U>. This Lease shall be binding on the Landlord, Tenant and their
respective successors and assigns. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.11&nbsp;&nbsp;&nbsp;&nbsp;<U>Relationship</U>. The relationship of Landlord and
Tenant is solely that of independent third parties engaged in an arms-length transaction. Nothing contained in this Lease shall be deemed or construed as creating a partnership, joint venture, agency or other similar relationship between Landlord
and Tenant. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.12&nbsp;&nbsp;&nbsp;&nbsp;<U>Severability</U>. If any provision of this Lease is found by a court of
competent jurisdiction to be illegal, invalid or unenforceable, the remainder of this Lease will not be affected, and in lieu of each provision that is found to be illegal, invalid or unenforceable, a provision will be added as a part of this Lease
that is as similar to the illegal, invalid or unenforceable provision as may be possible and be legal, valid and enforceable. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.13&nbsp;&nbsp;&nbsp;&nbsp;<U>Entire Agreement</U>. This Lease constitutes the entire agreement between the parties with
respect to the Premises, and all prior negotiations and understandings shall be deemed incorporated herein. This Lease may only be amended or modified by a written instrument signed by both Landlord and Tenant. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.14&nbsp;&nbsp;&nbsp;&nbsp;<U>No Waiver</U>. No waiver by Landlord or Tenant of any provision or breach of this Lease shall
be deemed to have been made unless the same is in writing, and no waiver of any provision or breach of this Lease shall be deemed a waiver of any other provision or breach. Landlord&#146;s or Tenant&#146;s consent to or approval of any act shall not
be deemed to render unnecessary the obtaining of Landlord&#146;s or Tenant&#146;s consent to or approval of any subsequent act. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.15&nbsp;&nbsp;&nbsp;&nbsp;<U>Submission</U>. The submission of this Lease does not constitute an offer, and this document
shall become effective and binding only upon the execution and delivery hereof by both Landlord and Tenant. Furthermore, copies of this Lease that have not been executed and delivered by both Landlord and Tenant shall not serve as a memorandum or
other writing evidencing an agreement between the parties. It is hereby disclosed that only the officer of Tenant listed in the signature block of this Lease has the authority to cause Tenant to enter into binding leases. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.16&nbsp;&nbsp;&nbsp;&nbsp;<U>Memorandum of Lease</U>. Upon either party&#146;s written request, Landlord and Tenant shall
promptly execute and record a memorandum of this Lease in substantially the form attached as <B><U>Exhibit&nbsp;L</U></B>; provided the cost of recording such memorandum shall be borne by the requesting party. This Lease shall not be recorded in its
entirety unless Landlord and Tenant agree otherwise, in writing. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.17&nbsp;&nbsp;&nbsp;&nbsp;<U>Attorney Fees</U>. In
the event of any lawsuit between the parties arising from or relating to this Lease, the prevailing party in such lawsuit shall be entitled to recover its reasonable costs, expenses and attorneys&#146; fees from the
<FONT STYLE="white-space:nowrap">non-prevailing</FONT> party therein, including, but not limited to, court costs, professional fees and other litigation expenses through all appellate levels and in bankruptcy court. This section shall survive the
expiration or termination of this Lease. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-38- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.18&nbsp;&nbsp;&nbsp;&nbsp;<U>Exhibits</U>. Landlord and Tenant acknowledge and
agree that all exhibits and addenda referenced in this Lease are attached hereto and incorporated herein by reference. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.19&nbsp;&nbsp;&nbsp;&nbsp;<U>Governing Law</U>. This Lease shall be governed by the laws of the State of Missouri. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.20&nbsp;&nbsp;&nbsp;&nbsp;<U>WAIVER OF TRIAL BY JURY</U>. EACH OF LANDLORD AND TENANT HEREBY EXPRESSLY WAIVES ANY RIGHT TO
TRIAL BY JURY OF ANY CLAIM, DEMAND, ACTION OR CAUSE OF ACTION (i)&nbsp;ARISING UNDER THIS LEASE (OR ANY AGREEMENT FORMED PURSUANT TO THE TERMS HEREOF) OR (ii)&nbsp;IN ANY MANNER CONNECTED WITH OR RELATED OR INCIDENTAL TO THE PREMISES, THE DEALINGS
OF LANDLORD AND TENANT WITH RESPECT TO THIS LEASE (OR ANY AGREEMENT ENTERED INTO PURSUANT TO THE TERMS HEREOF) OR ANY OTHER INSTRUMENT, DOCUMENT OR AGREEMENT EXECUTED OR DELIVERED IN CONNECTION WITH THIS LEASE OR THE TRANSACTIONS CONTEMPLATED
HEREIN, WHETHER NOW EXISTING OR HEREINAFTER ARISING, AND WHETHER SOUNDING IN CONTRACT, TORT OR OTHERWISE. EITHER PARTY MAY FILE A COPY OF THIS SECTION WITH ANY COURT AS CONCLUSIVE EVIDENCE OF THE CONSENT OF EACH SUCH PARTY TO THE WAIVER OF ITS RIGHT
TO TRIAL BY JURY. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.21&nbsp;&nbsp;&nbsp;&nbsp;<U>Time</U>. For purposes of this Lease (including, without limitation,
all exhibits hereto), TIME SHALL BE CONSIDERED OF THE ESSENCE. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.22&nbsp;&nbsp;&nbsp;&nbsp;<U>Limitation Upon
Landlord&#146;s Liability</U>. Notwithstanding anything to the contrary contained in this Lease, the liability of Landlord to Tenant for the default by Landlord under the terms of this Lease shall be limited to Tenant&#146;s actual, but not
consequential, damages and shall be recoverable only from Landlord and Guarantor. Landlord&#146;s shareholders, partners, members, officers and directors other than Guarantor shall have no personal liability whatsoever under this Lease, except as
expressly provided in any separate written agreement executed by any of the foregoing Persons. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">26.23&nbsp;&nbsp;&nbsp;&nbsp;<U>Due Diligence Costs</U>. Upon the earlier to occur of December&nbsp;15, 2017 or the date
Tenant closes the Construction Loan, Tenant shall pay Landlord the sum of Sixty Thousand Three Hundred Forty and No/100 Dollars ($60,340.00) to compensate Tenant for certain due diligence costs and other expenses incurred by Tenant in connection
with the Project. In addition, Landlord hereby agrees to pay, when due, all of the costs and expenses described on <B><U>Exhibit&nbsp;M</U></B>. </P>
 <p STYLE="margin-top:0pt;margin-bottom:0pt ; font-size:8pt">&nbsp;</P> <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">-39- </P>


<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">IN WITNESS WHEREOF, Landlord and Tenant have duly executed this Lease as of the
date first above written. </P> <P STYLE="font-size:12pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P><DIV ALIGN="right">
<TABLE CELLSPACING="0" CELLPADDING="0" WIDTH="40%" BORDER="0" STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:10pt">


<TR>
<TD WIDTH="12%"></TD>
<TD VALIGN="bottom" WIDTH="1%"></TD>
<TD WIDTH="87%"></TD></TR>


<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top" COLSPAN="3">LANDLORD:</TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="16" COLSPAN="3"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top" COLSPAN="3">RYAN BOONE COUNTY, LLC</TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="16"></TD>
<TD HEIGHT="16" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top">By:</TD>
<TD VALIGN="bottom" STYLE=" BORDER-BOTTOM:1px solid #000000">&nbsp;</TD>
<TD VALIGN="top" STYLE="BORDER-BOTTOM:1px solid #000000">&nbsp;</TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top">Name:</TD>
<TD VALIGN="bottom" STYLE=" BORDER-BOTTOM:1px solid #000000">&nbsp;</TD>
<TD VALIGN="top" STYLE="BORDER-BOTTOM:1px solid #000000">&nbsp;</TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top">Title:</TD>
<TD VALIGN="bottom" STYLE=" BORDER-BOTTOM:1px solid #000000">&nbsp;</TD>
<TD VALIGN="top" STYLE="BORDER-BOTTOM:1px solid #000000">&nbsp;</TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="16" COLSPAN="3"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top" COLSPAN="3">TENANT:</TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="16" COLSPAN="3"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top" COLSPAN="3">SMITH&nbsp;&amp; WESSON CORP.</TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="16"></TD>
<TD HEIGHT="16" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top">By:</TD>
<TD VALIGN="bottom" STYLE=" BORDER-BOTTOM:1px solid #000000">&nbsp;</TD>
<TD VALIGN="top" STYLE="BORDER-BOTTOM:1px solid #000000">&nbsp;</TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top">Name:</TD>
<TD VALIGN="bottom" STYLE=" BORDER-BOTTOM:1px solid #000000">&nbsp;</TD>
<TD VALIGN="top" STYLE="BORDER-BOTTOM:1px solid #000000">&nbsp;</TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top">Title:</TD>
<TD VALIGN="bottom" STYLE=" BORDER-BOTTOM:1px solid #000000">&nbsp;</TD>
<TD VALIGN="top" STYLE="BORDER-BOTTOM:1px solid #000000">&nbsp;</TD></TR>
</TABLE></DIV>
</BODY></HTML>
</TEXT>
</DOCUMENT>
<DOCUMENT>
<TYPE>EX-10.115
<SEQUENCE>3
<FILENAME>d479247dex10115.htm
<DESCRIPTION>EX-10.115
<TEXT>
<HTML><HEAD>
<TITLE>EX-10.115</TITLE>
</HEAD>
 <BODY BGCOLOR="WHITE">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="right"><B>Exhibit 10.115 </B></P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">GUARANTY </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">THIS
GUARANTY (this &#147;Guaranty&#148;) is entered into by the undersigned (&#147;Guarantor&#148;) this 26<SUP STYLE="font-size:85%; vertical-align:top">th</SUP> day of October, 2017 (the &#147;Effective Date&#148;). </P>
<P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">RECITALS </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">WHEREAS, Ryan Boone County, LLC (&#147;Landlord&#148;) and Smith&nbsp;&amp; Wesson Corporation (&#147;Tenant&#148;) are
parties to that certain Lease Agreement dated of even date herewith (the &#147;Lease&#148;). </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">WHEREAS, Landlord has agreed
to execute the Lease on the condition that the undersigned Guarantor execute this Guaranty in favor of Landlord. </P> <P STYLE="margin-top:18pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">AGREEMENT </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">NOW, THEREFORE, in consideration of the Lease and other good and valuable consideration, the receipt and sufficiency of which
are hereby acknowledged, the undersigned agrees as follows for the benefit of Landlord: </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">1.&nbsp;&nbsp;&nbsp;&nbsp;For
purposes hereof, including, but not limited to, the foregoing recitals, all capitalized terms used, but not defined, in this Guaranty shall have the meaning ascribed to them in the Lease. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">2.&nbsp;&nbsp;&nbsp;&nbsp;Subject to the other terms hereof, Guarantor hereby: (i)&nbsp;guarantees to the Landlord, its
successors and assigns, the full and prompt payment of all amounts due from Tenant to Landlord under and pursuant to said Lease during the Term, and the full performance and observance of all the covenants, terms, conditions and agreements therein
provided to be performed and observed by the Tenant, its successors and assigns, under the Lease during the Term; and (ii)&nbsp;agrees that if default shall at any time be made by the Tenant, its successors and assigns, in the payment or in the
performance of any of the terms, covenants, provisions or conditions contained in said Lease during the Term, then Guarantor will forthwith make such payments due to the Landlord, its successors and assigns, under the Lease during the Term and will
forthwith faithfully perform and fulfill all of such terms, covenants, conditions and provisions arising under the Lease during the Term, including, without limitation, the payment to the Landlord of all actual damages recoverable by Landlord under
the Lease as a result of a Tenant Default, but excluding damages that are not recoverable under the Lease as a result of the limitations set forth therein. If Landlord notifies Tenant that it is in default under the Lease during the Term, Landlord
shall simultaneously give written notice of such default to Guarantor, at the address set forth herein, and Guarantor shall the right to remedy such default within the cure periods provided in the Lease; provided, such cure periods shall not
commence until Landlord gives Guarantor written notice of such default. Landlord shall accept Guarantor&#146;s cure of any such default, and no Tenant Default shall arise therefrom in the event such default is timely cured. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">3.&nbsp;&nbsp;&nbsp;&nbsp;This Guaranty is an absolute and unconditional Guaranty of payment and of performance. It shall be
enforceable against the Guarantor, his or her successors and assigns, without the necessity for any suit or proceedings on the Landlord&#146;s part of any kind or nature whatsoever against the Tenant, its successors and assigns, and without the
necessity of any notice of <FONT STYLE="white-space:nowrap">non-payment,</FONT> <FONT STYLE="white-space:nowrap">non-performance</FONT> or <FONT STYLE="white-space:nowrap">non-observance</FONT> or any notice of acceptance of this Guaranty or any
other notice or demand to which the Guarantor might otherwise be entitled, all of which the Guarantor hereby expressly waives except as otherwise provided in the Lease or herein; and the Guarantor hereby expressly agrees that the validity of this
Guaranty and the obligations of the Guarantor hereunder shall in no way be terminated, affected or impaired by reason of the assertion or the failure to assert by the Landlord against the Tenant, or the
</P>

<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
Tenant&#146;s successors and assigns, of any of the rights or remedies reserved to the Landlord pursuant to the provisions of said Lease. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">4.&nbsp;&nbsp;&nbsp;&nbsp; </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(a)&nbsp;&nbsp;&nbsp;&nbsp;If Tenant assigns the Lease and is fully released from its obligations and liabilities under the
Lease by written agreement from Landlord or by the express terms of the Lease, then Guarantor shall be released from its obligations and liabilities under this Guaranty. If Tenant assigns the Lease and is partially released from its obligations and
liabilities under the Lease (the &#147;Released Obligations&#148;) by written agreement from Landlord or by the express terms of the Lease (including, but not limited to, Section&nbsp;14.01 of the Lease), then Guarantor shall have no obligations or
liabilities under this Guaranty with respect to the Released Obligations. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">(b)&nbsp;&nbsp;&nbsp;&nbsp;For purposes hereof:
</P> <P STYLE="margin-top:6pt; margin-bottom:0pt; margin-left:4%; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">&#147;Assumption Agreement&#148; means a written agreement pursuant to which any Person assumes, in whole
or in part, the obligations of Guarantor under this Guaranty for the benefit of Landlord. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; margin-left:4%; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">&#147;Net
Worth&#148; means, with respect to any Person, the difference between such Person&#146;s total assets and its total liabilities, excluding the amount of any negative goodwill and calculated in accordance with generally accepted accounting principles
or other reputable accounting principles. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; margin-left:4%; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">&#147;Qualified Replacement Guarantor&#148; means any Person
that (i)&nbsp;has either a current long term unsubordinated debt rating of &#147;BBB&#148; or higher from Standard&nbsp;&amp; Poor&#146;s Corporation (&#147;Standard&nbsp;&amp; Poor&#146;s&#148;) or a long term unsubordinated debt rating of
&#147;Baa&#148; or higher from Moody&#146;s Investor Services (&#147;Moody&#146;s&#148;) or a similar or higher rating published by a nationally recognized and reputable ratings agency or financial services firm or a similar or better
creditworthiness evaluation prepared by a qualified financial services firm or national accounting firm; and (ii)&nbsp;has a Net Worth that equals or exceeds the Net Worth of Guarantor on the Effective Date. If Standard&nbsp;&amp; Poor&#146;s or
Moody&#146;s ceases to publish such debt ratings, Guarantor may substitute a similar debt rating scale published by a nationally recognized and reputable ratings agency or financial services firm for the same. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; margin-left:4%; text-indent:8%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">&#147;Substitute Guaranty&#148; means an agreement, in substantially the form of this Guaranty, pursuant to
which any Person guarantees, in whole or in part, the satisfaction of Tenant&#146;s liabilities under the Lease for the benefit of Landlord. </P>
<P STYLE="margin-top:12pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">If a Qualified Replacement Guarantor executes an Assumption Agreement or a Substitute Guaranty covering all of
Guarantor&#146;s obligations under this Guaranty, then Guarantor shall be released from its obligations and liabilities under this Guaranty. If a Qualified Replacement Guarantor executes an Assumption Agreement under which it partially assumes
Guarantor&#146;s obligations under this Guaranty or a Substitute Guaranty partially covering Guarantor&#146;s obligations under this Guaranty, then Guarantor shall be released from its obligations and liabilities under this Guaranty, to the extent,
but only to the extent, the same are assumed by such Qualified Replacement Guarantor or covered by such Substitute Guaranty. Any release of Guarantor pursuant to this paragraph shall only be effective upon the delivery of the applicable Assumption
Agreement or Substitute Guaranty to Landlord. </P>

<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">5.&nbsp;&nbsp;&nbsp;&nbsp;All notices, consents, approvals and other
communications (collectively, &#147;Notices&#148;) that may be or are required to be given by either Guarantor or Landlord under this Guaranty shall be properly made only if in writing and sent to the address of Guarantor or Landlord, as applicable,
set forth below, as the same is modified in accordance herewith, by hand delivery, U.S. Certified Mail (Return Receipt Requested) or nationally recognized overnight delivery service. </P>
<P STYLE="font-size:6pt;margin-top:0pt;margin-bottom:0pt">&nbsp;</P>
<TABLE CELLSPACING="0" CELLPADDING="0" WIDTH="84%" BORDER="0" STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:10pt" ALIGN="center">


<TR>
<TD WIDTH="13%"></TD>
<TD VALIGN="bottom" WIDTH="3%"></TD>
<TD WIDTH="84%"></TD></TR>


<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">If&nbsp;to&nbsp;Guarantor:</P></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">American Outdoor Brands Corporation</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">c/o Smith&nbsp;&amp; Wesson Corp.</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">2100 Roosevelt Avenue</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Springfield, MA 01104</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Attn: Robert J. Cicero</P></TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="8"></TD>
<TD HEIGHT="8" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">with a copy to:</P></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Smith&nbsp;&amp; Wesson Corp.</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">2100 Roosevelt Avenue</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Springfield, MA 01104</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Attn: Lewis Hornsby</P></TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="8"></TD>
<TD HEIGHT="8" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">If to Landlord:</P></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Ryan Boone County, LLC</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">c/o Ryan Companies US, Inc.</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">533 South Third Street, Suite 100</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Minneapolis, MN 55415</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Attn: Casey Hankinson</P></TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="8"></TD>
<TD HEIGHT="8" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">with Copy to:</P></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Ryan Companies US, Inc.</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">533 South Third Street, Suite 100</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Minneapolis, MN 55415</P></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top"></TD>
<TD VALIGN="bottom">&nbsp;&nbsp;</TD>
<TD VALIGN="top"> <P ALIGN="justify" STYLE=" margin-top:0pt ; margin-bottom:0pt; font-family:Times New Roman; font-size:10pt">Attn: Audra Williams</P></TD></TR>
</TABLE> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">Either Guarantor or Landlord may change its address for Notices by giving a ten (10)&nbsp;day
prior written notice to the other party in accordance with this provision. Notices shall be deemed received on the date of actual delivery; provided if either Guarantor or Landlord refuses to accept the delivery of any Notice, such notice shall be
deemed to have been actually delivered on the date of such refusal. </P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">6.&nbsp;&nbsp;&nbsp;&nbsp;This Guaranty will be
interpreted by and construed under the laws of the State of Missouri. Guarantor: (i)&nbsp;agrees that any suit, action or other legal proceeding arising out of or relating to this instrument shall be brought in a court of record in the State of
Missouri or in the Courts of the United States of America having jurisdiction over the State of Missouri, (ii)&nbsp;consents to the jurisdiction of each such court in any such suit, action or proceeding and (iii)&nbsp;waives any objection which
Guarantor may have to the laying of venue of any suit, action or proceeding in any of such courts and any claim that any such suit, action or proceeding has been brought in an inconvenient forum. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">7.&nbsp;&nbsp;&nbsp;&nbsp;In the event any one or more of the provisions contained in this instrument or any application
thereof shall be invalid, illegal, or unenforceable in any respect, the validity, legality or enforceability of the remaining provisions of this instrument and any other application thereof shall not in any way be affected or impaired. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">8.&nbsp;&nbsp;&nbsp;&nbsp;Except as otherwise expressly provided herein, this Guaranty shall be a continuing Guaranty, and the
liability of the Guarantor hereunder shall in no way be affected, modified or diminished by reason of any assignment of the Lease, any extension of the Lease pursuant to the terms thereof, or by reason of any waiver of any of the terms, covenants,
conditions or provisions of said Lease by Landlord, or </P>

<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <P STYLE="margin-top:0pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="justify">
by reason of any extension of time that may be granted by the Landlord to the Tenant, its successors or assigns. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">9.&nbsp;&nbsp;&nbsp;&nbsp;The Guaranty shall be binding upon and inure to the benefit of the successors and assigns of
Guarantor and Tenant. Any references to Guarantor, Tenant and Landlord shall be deemed to mean and include the party and its respective successors and assigns. Landlord shall have the right to assign and transfer this Guaranty to any Person to whom
it assigns its rights under the Lease. Landlord&#146;s successors and assigns shall have the rights, elections, remedies, privileges, discretions and powers granted under this Guaranty to Landlord and the right to rely upon this Guaranty in the same
manner and with the same force and effect as if they were specifically named as Landlord herein. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">10.&nbsp;&nbsp;&nbsp;&nbsp;This Guaranty constitutes the entire agreement and understanding of Guarantor and Landlord with
respect to the subject matter hereof and supersedes all prior agreements, understandings, letters, negotiations and discussions, whether oral or written. This Guaranty may be amended only by a written instrument executed by Guarantor and Landlord.
</P> <P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">11.&nbsp;&nbsp;&nbsp;&nbsp;No waiver of any provision of this Guaranty shall be deemed to have been made unless expressed
in writing and signed by the party charged therewith. The failure of Landlord to insist in any one or more instances upon the strict performance of any of the provisions of this Guaranty or to take advantage of any of its rights under this Guaranty
shall not be construed as a waiver of any such provisions or the relinquishment of any such rights, rather the same shall continue and remain in full force and effect. No delay or omission in the exercise of any remedy accruing upon the breach of
this Guaranty shall impair such remedy or be construed as a waiver of such breach. The waiver by Landlord of any breach of this Guaranty shall not be deemed a waiver of any other breach of the same or any other provision hereof. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">12.&nbsp;&nbsp;&nbsp;&nbsp;Whenever the context may require, any pronoun used in this Guaranty shall include the masculine,
feminine and neuter forms. All references to articles, sections and paragraphs shall be deemed references to the articles, sections and paragraphs of this Guaranty, unless the context shall indicate otherwise. The terms &#147;hereof&#148;,
&#147;hereunder&#148; and similar expressions refer to this Guaranty as a whole and not to any particular article, section or paragraph contained herein. The titles of the articles, sections and paragraphs of this Guaranty are for convenience only
and shall not affect the meaning of any provision hereof. Guarantor and Tenant have agreed to the particular language of this Guaranty, and any question regarding the meaning of this Guaranty shall not be resolved by a rule providing for
interpretation against the party who caused the uncertainty to exist or against the draftsman. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">13.&nbsp;&nbsp;&nbsp;&nbsp;In the event any legal proceeding is commenced related to this Guaranty, the prevailing party in
such proceeding shall be entitled to recover its reasonable attorneys&#146; fees, court costs and litigation expenses from the <FONT STYLE="white-space:nowrap">non-prevailing</FONT> party therein. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">14.&nbsp;&nbsp;&nbsp;&nbsp;GUARANTOR HEREBY EXPRESSLY WAIVES ITS RIGHT TO A TRIAL BY JURY OF ANY CLAIM ARISING UNDER THIS
GUARANTY, WHETHER NOW EXISTING OR HEREAFTER ARISING. LANDLORD MAY FILE AN ORIGINAL OR A COPY OF THIS SECTION WITH ANY COURT AS WRITTEN EVIDENCE OF THE FOREGOING WAIVER. </P>
<P STYLE="margin-top:6pt; margin-bottom:0pt; text-indent:4%; font-size:10pt; font-family:Times New Roman" ALIGN="justify">15.&nbsp;&nbsp;&nbsp;&nbsp;Guarantor acknowledges that Landlord has made no oral statements to Guarantor that could be
construed as a waiver of Landlord&#146;s right to enforce this Guaranty by all available legal means. </P> <P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">[<I>Signature to follow</I>] </P>

<p Style='page-break-before:always'>
<HR  SIZE="3" style="COLOR:#999999" WIDTH="100%" ALIGN="CENTER">

 <DIV ALIGN="right">
<TABLE CELLSPACING="0" CELLPADDING="0" WIDTH="40%" BORDER="0" STYLE="BORDER-COLLAPSE:COLLAPSE; font-family:Times New Roman; font-size:10pt">


<TR>
<TD WIDTH="12%"></TD>
<TD VALIGN="bottom" WIDTH="1%"></TD>
<TD WIDTH="87%"></TD></TR>


<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top" COLSPAN="3">GUARANTOR:</TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="16" COLSPAN="3"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top" COLSPAN="3">AMERICAN OUTDOOR BRANDS CORPORATION</TD></TR>
<TR STYLE="font-size:1pt">
<TD HEIGHT="16"></TD>
<TD HEIGHT="16" COLSPAN="2"></TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top">By:</TD>
<TD VALIGN="bottom" STYLE=" BORDER-BOTTOM:1px solid #000000">&nbsp;</TD>
<TD VALIGN="top" STYLE="BORDER-BOTTOM:1px solid #000000">&nbsp;</TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top">Name:</TD>
<TD VALIGN="bottom" STYLE=" BORDER-BOTTOM:1px solid #000000">&nbsp;</TD>
<TD VALIGN="top" STYLE="BORDER-BOTTOM:1px solid #000000">&nbsp;</TD></TR>
<TR STYLE="page-break-inside:avoid ; font-family:Times New Roman; font-size:10pt">
<TD VALIGN="top">Title:</TD>
<TD VALIGN="bottom" STYLE=" BORDER-BOTTOM:1px solid #000000">&nbsp;</TD>
<TD VALIGN="top" STYLE="BORDER-BOTTOM:1px solid #000000">&nbsp;</TD></TR>
</TABLE></DIV> <P STYLE="margin-top:12pt; margin-bottom:0pt; font-size:10pt; font-family:Times New Roman" ALIGN="center">[Signature Page to Guaranty] </P>
</BODY></HTML>
</TEXT>
</DOCUMENT>
</SEC-DOCUMENT>
